HomeMy WebLinkAboutSoutheast Fresno RAD HOME Program Cedar Court sand InyoTerrace Apartments"ùRecorded at the Request of
and When Recorded Return to:
hecordlno roquðsted by!
PLAOEN ÏIf LE COITPAIIY
Lto1"27,t7aøL
City of Fresno
City Clerk's Office
2600 Fresno Street, Room 2133
Fresno, CA 93721-3603
a/nþq j
lllltl I ilil il il il ilil il il il ll il I ilfi I ilil I ilt
FRESltl0 Countv Recorder
Paul Oictos,
'C,
P, A,Doc- 2øt3-0 t72?46
Check Number Zll9J622
Tuesday, DEC 24, 2ø13 1Ø:19:16
Ttl Pd g0 00 Rcpt il 00ø4øZBtlø
JZ'G/R3/ 1-ÊE
.:.(u
.t;o 3-'
L)-L.t otl.:_
u()Ç:ø
l: ìuocr
).-
¿i
This Agreement is recorded at the request and for the.benefit of the City of Fresno and ¡s exemptfrom the peyment of a recording fee pursuant to Government C;de Section 6103
CITY OF FRESNO
By:
Date:
CITY OF FRESNO
HOME INVESTMENT PARTNERSHIPS PROGRAM
AGREEMENT
by and between
CITY OF FRESNO,
a municipal corporation
and
southeast Fresno RAD, Lp, a california limited partnership
regarding
cedar courts Apartments Fresno RentalAssistance Demo_nstration (RAD) Rehabilitation project
4216 E. Hamilton Avenue, South East Fresno, CA 93702 (A.P.N.ì 47L212-01T, 471-211-
01T, and portion of 471-220-01T)
and
lnyo Terrace Apartments Fresno RentalAssistance Demonstration (RAD) Rehabilitation project
510 S. Peach Avenue, South East Fresno, CA 93722 (ApN: +6g-OSO-ZZil
TABLE OF CONTENTS
paqe
RECTTALS ............ 3
ARTTCLE 1. DEF|N|TIONS ........... ......4
ARTICLE 2. TERMS .......,...7
ARTICLE 3. REPRESENTATION AND WARRANTIES OF DEVELOPER. ........ 9
ARTTCLE 4. COVENANTS OF THE DEVELOPER .......... ................ 1O
ARTICLE 5. PROPERTY MAINTENANCE ....... 15
ARTICLE 6. DISBRUSEMENT OF HOME FUNDS.... ....... 19
ARTICLE 7. REHABILITATION PROJECT .......21
ARTTCLE 8. OPERATTONS OF THE PROJECT ............... 25
ARTICLE 9. INSURANCEAND INDEMNITYAND BONDS.... ..........28
ARTTCLE 10. DEFAULTAND REMED|ES..... ...................33
ARTTCLE 11. GENERAL PROVISIONS. ...........35
HOME INVESTMENT PARTNERSHIPS PROGRAM AGREEMENT
This HOME lnvestment Partnerships rogram Agreement (hereinafter referred to as
the "Agreement") is entered into this,,2013, by and between the City of
Fresno, a municipal corporation, acting" ihrough its Development and Resource
Management Department - Housing and Community Development Division (hereinafter
referred to as the "C|TY"), and Southeast Fresno RAD, LP, a California limited partnership
(hereinafter referred to as "DEVELOPER').
RECITALS
A. WHEREAS, the CITY has received a HOME lnvestment Partnerships ("HOME")
Program grant from the U.S. Department of Housing and Urban Development (hereinafter
referred to as ('HUD"), under Title ll of the Cranston-Gonzalez National Affordable Housing
Act of 1990, as amended (hereinafter referred to as the "Act').
B. WHEREAS, to advance the supply of Affordable rental housing within the City of
Fresno the CITY desires, among other things, to encourage investment in the affordable
housing market.
C. WHEREAS, the DEVELOPER desires to rehabilitate the Cedar Courts and lnyo
Terrance Apartments and related on-site improvements (collectively the "Property") located
within the boundaries of the City of Fresno, as more particularly described in EXHIBIT uA'-
Property Description, (hereinafter referred to as the "Project").
D. WHEREAS, the DEVELOPER desires to act as the owner/developer exercising
effective project control, as to the rehabilitation and related on-site improvements of one
hundred forty-nine (149) units in the Cedar Courts Apartments and forty-four (44) units in
the lnyo Terrace Apartments of which nine (9) will be a HOME-assisted units to be
preserved as Low-lncome rental housing, as defined by the HOME Program, as more
particularly described in EXHIBIT "B'- Project Description and Schedule, incorporated
herein.
E. WHEREAS, the Project will be rehabilitated upon HOME Program eligible Property
owned by the DEVELOPER.
F. WHEREAS, to further its goal to increase the supply of Affordable Housing within
the City of Fresno, the CITY desires to provide HOME Program funding assistancé to the
Project as a one Million Five Hundred Thousand dollars and 0o/1oo ($1,50o,ooo.oo)
residual receipts loan at 4% interest for a term of fifty-five (55) years for eligible HOME
Project rehabilitation costs, upon the terms and conditions in this Agreement, as further
identÍfied in EXHIBIT "C'- Budget, to be secured by the underlying Property and the
Affordable Housing covenants attached as EXHIBIT uD" - Exemplar Declaration of
Restriction, and Note, Exemplar Notes attached as EXHIBIT "Fu - Promissory Note loan,
upon the terms and conditions in this Agreement.
G. WHEREAS, the CITY conducted an environmental review of the Project pursuant to
the California Environmental Quality Act ("CEQA") guidelínes on March 6, 2þ13, which
resulted in a Categorical Exemption. Additionally, the CITY completed an environmental
review of the Project pursuant to the National Environmental Policy Act ("NEPA") guidelines
on January 24,2013, that resulted in a Finding of No Significant lmpact.
H. WHEREAS, the CITY has determined that this Agreement is in the best interest of,
and will materially contribute to, the Housing Element of the General Plan. Further, the
CITY has found that the Project: (i) will have a positive influence in the neighborhood and
surrounding environs, (ii) is in the vital and best interest of the CITY, and the health, safety,
and welfare of CITY residents, (iii) complies with applicable federal, State, and local laws
and requirements, (iv) will increase, improve, and preserve the community's supply of Low-
lncome Housing available at an affordable cost to Low-lncome household, as defined
hereunder, (v) planning and administrative expenses incurred in pursuit hereof are
necessary for the production, improvement, or preservation of Low-lncome Housing, and
(vi) will comply with any and all owner participation rules and criteria applicable thereto.
l. WHEREAS, the CITY and DEVELOPER have determined that the Project's HOME-
assisted Units constitute routine programmatic/grantee lender activities utilizing available
and allocated program/grantee funding, outside the reach of the California Constitution
Article XXXIV and enabling legislation.
J. WHEREAS, the parties acknowledge and agree that the obligations and liabilities of
the DEVELOPER hereunder shall be joint and several unless and except to any extent
expressly provided otherwise.
K. WHEREAS, on August 28, 2013, the Housing and Community Development
Commission of the City of Fresno reviewed this HOME Agreement and recommended
approval.
L. WHEREAS, 2013, the DEVELOPER'S Board reviewed and approved
the development of d HOME Agreement.
NOW, THEREFORE, lN CONSIDERATION of the above recitals, which recitals are
contractual in nature, the mutual promises herein contained, and for other good and
valuable consideration hereby acknowledge, the parties agree as follows:
ARTICLE 1. DEFINITIONS
The following terms have the meaning and content set forth in this Article wherever used in
this Agreement, attached exhibits or attachments that are incorporated into this Agreement
by reference.
1.1 Acquisition means vesting of the Property in fee title to the DEVELOPER.
1.2 ADA means the Americans with Disabilities Act of 1990, as most recently
amended.
1.3 Affirmative Marketinq means a good faith effort to attract eligible persons of
all racíal, ethnic and gender groups, in the housing market area, to purchase the proposed
Housing Unit that proposed for rehabilitation on the eligible Property, as hereinafter
defined.
1.4 Affordability Period means the minimum period of fifty-five (55) years
commencing from the date the CITY enters project completion information into HUD's
Integrated Disbursement and lnformation System (lDlS), which date will be provided to the
DEVELOPER by the CITY and added as an administrative amendment hereto; City agrees
to enter project completion information into lDlS within 30 days of City's receipt thereof.
1.5 Affordable Rental Housinq means nine (9) of the one hundred and ninety-
three (193) Housing units required to meet the affordability requirements of 24 C.F.R.
92.252.
1.6 Budoet means the pro-forma Budget, attached hereto as EXHIBIT 'C', for the
development of the Project, as may be amended upon the approval of the CITY's Housing
and Community Development Division Manager provided any increase in HOME Funds
hereunder requires City Council Approval.
1.7 Certificate of Gompletion means that certificate issued, in the form attached
as EXHIBIT "E" ("Exemplar Certificate of Completion"), to the DEVELOPER by the CITY
evidencing completion of the Project and a release of construction related covenants for
the purposes of the Agreement.
1.8 CFR means the Code of Federal Regulations.
1.9 Commencement of Rehabilitation means the time the DEVELOPER or the
DEVELOPER's construction contractor begins substantial physical work on the Property,
including, without limitation, delivery of materials and any work, beyond maintenance of the
Property in its status quo condition, which shall take place in accordance with the Project
Schedule.
1.10 Declaration of Restrictions means the Declaration of Restrictions in the form
attached hereto as EXHIBIT "D", which contains the Affordability covenants and
requirements of this Agreement which shall run with the land and which the DEVELOPER
shall record or cause to be recorded against the Property no later than the date of
Commencement of Rehabilitation.
1.11 Deed of Trust means that standard form Deed of Trust (including the security
agreement) given by the DEVELOPER as Trustor, to the CITY as benefTciary attached as
EXHIBIT "G" to the Note and acceptable to the City Attorney, as well as any amendments
to, modification of and restatements of said Deed of Trust, which Deed of Trust shall be
subordinated to Project lenders per the Budget attached as EXHIBIT "C". There terms of
any such Deed of Trust are hereby incorporated into this Agreement by this reference.
1.12 Elioible Costs means the HOME eligible Property rehabilitation costs funded
by the Loan, consistent with the Project Budget attached as EXHIBIT "C', allowable under
24 C.F.R. Paft 92, as specified in 24 C.F.R. 92.205 and 92.206, and not disallowed by 24
C.F.R. 92.214, provided, however, that costs incuned in connection with any activity that is
determined to be ineligible under the Program by HUD or the CITY shall not constitute
Eligible Costs.
1 .13 Event of Default shall have the meaning assigned to such term under Section
10.1 hereunder.
1.14 Familv has the same meaning given that term in 24 C.F.R. 5.403.
1.15 Fundino Sources means the CITY's HOME Funds, the DEVELOPER's funds,
and any other funds that may become available to the Project.
1.16 Hazardous Materials means any hazardous or toxic substances, materials,
wastes, pollutants or contaminants which are defined, regulated or listed as "hazardous
substances," "hazardous wastes," "hazardous materials," "pollutants," "contaminants" or
"toxic substances" under federal or state environmental and health safety laws and
regulations, including without limitation, petroleum and petroleum byproducts, flammable
explosives, urea formaldehyde insulation, radioactive materials, asbestos and lead.
Hazardous Materials do not include substances that are used or consumed in the normal
course of developing, operating or occupying a housing project, to the extent and degree
that such substances are stored, used and disposed of in the manner and in amounts that
are consistent with normal practice and legal standards.
1.17 HOME Investment Partnerships Funds (also referred to in this Agreement as
HOME Funds) means the HOME Program monies consisting of the Loan in an amount notto exceed the sum of One Million Five Hundred Thousand dollars and 00/1OO
($1,500,000.00) to be used for eligible Project rehabilitation costs, pursuant to this
Agreement.
1.18 Household means one or more persons occupying a Unit within the Project.
1.19 HUD means the United States Department of Housing and Urban
Development.
1.20 Loan means the assumable Project Loan of HOME Funds, in the total amount
not to exceed the lesser of (i) One Million Five Hundred Thousand dollars and 00/100
($1,500,000.00) or (ii) the aggregate HOME per unit cap (24 CFR 92.250) forthe HOME-
assisted Units as determined by the CITY and made available by the CITY to the Project
pursuant to this Agreement, as more specifically described in the Budget and in the
Promissory Note attached as EXHIBIT'F'. The Loan shall be payable in accordance with
the terms of the Note, shall be secured by a deed of trust attached as EXHIBIT "G".
1.21 Loan Documents are collectively this Agreement, the Note (attached heretoas EXHIBIT "F"), Deed of Trust, Declaration of Restrictions, and all related
documents/instruments as they may be amended, modified or restated from time to time
along with all exhibits and attachments thereto, relative to the Loan.
1.22 Low-lncome Household means families whose annual income does not
exceed eighty percent (80%) of the median income for the Fresno, California area as
determined by HUD, except as HUD may establish income ceilings higher or lower than
eighty percent (80%) of the median for the area on the basis of HUD finding that such
variations are necessary.
1.23 Note means that certain assumable, HOME Loan Note in a principal amount
not to exceed the HOME Program per unit cap (24 C.F.R. 92.250) as determined by the
CITY, given by the DEVELOPER as promissor, in favor of the CITY as promisee,
evidencing the Loan and performance of the affordability and other covenants and
restrictions set forth in this Agreement, secured by the Deed of Trust as 3'd position lien
upon the Property, naming the CITY as beneficiary and provided to the CITY, no later than
the date of the Affordable Project funding hereunder, an exemplar of which is attached
hereto as EXHIBIT "F", and incorporated herein, as well as any amendments to,
modifications of and restatements of said Note consented to by the CITY.
1.24 Proqram lncome has the meaning provided in the HOME Program including
24 C.F.R. 92.503.
1.25 Project means the rehabilitation of the Cedar Court Apartments located at
4216 E. Hamilton Avenue, Fresno, CA93702 and Inyo Terrance Apartments located at 510
S. Peach, Fresno, CA 93727, and related on-site improvements all as described in the
Project Description and Schedule attached hereto and incorporated herein as EXHIBIT'8"
upon the property as more particularly described in EXHIBIT "4".
1.26 Proiect Completion Date means the date that the CITY shall have determined
that the Project: 1) has reached completion in accordance with the scope of work as
approved by the CITY; 2) is in compliance with all Housing Standards, and 3) has been
issued a Certificate of Occupancy, 4) final Project costs and Household information is
entered into lDlS.
1.27 Proiect Schedule means the schedule for commencement and completion
and close of escrow of the Project included in EXHIBIT "8".
1.28 Propertv means 4216 E. Hamilton, Fresno, CA 93702 (APN: 471-212-01T,
471-211-01T, and portion oÍ 471-220-01T) and 510 South Peach Avenue, Fresno, CA
93727 (A.P.N.: 463-050-22T), more specifically described in the Property Descriptions
attached to EXHIBIT "A'.
1.29 Unit means the one hundred and ninety-three (193) affordable rental housing
units of which nine (9) Units shall be HOME-assisted Affordable rental Housing Units to be
rehabilitated upon the Property and preserved as Affordable Housing for the duration of the
fifty-five (55) year Affordability Period.
ARTICLE 2. TERMS OF THE LOAN
2.1 Loan of HOME Funds. The CITY agrees to provide a Loan of HOME Funds
to the DEVELOPER in an amount not to exceed One Million Five Hundred Thousand
dollars and 00/100 ($1,500,000.00) under the terms and conditions provided in this
Agreement. The HOME Funds shall be used for payment of HOME Eligible Costs.2.2 Loan Documents. The DEVELOPER shall execute and deliver the Loan
Documents including the Note to the CITY, and the notarized Deed of Trust to Placer Title
Company for recordation against the Property, as provided for in this Agreement.
2.3 Term of Aoreement. This Agreement is effective upon the date of execution
and shall remain in force with respect to the Project for the duration of the Affordability
Period unless earlier terminated as provided herein. After the fifty-five (55) year
AffordabiliÇ Period, this Agreement will expire. lt is understood and agreed upon,
however, that if for any reason this Agreement should be terminated in whole or in part as
provided hereunder, without default, by the DEVELOPER prior to disbursement of HOME
Program funding hereunder, the CITY agrees to record a Notice of Cancellation regardíng
this Agreement, upon the written request of the DEVELOPER.
2.4 Loan Repayment and Maturity. The Loan will be due and payable in
accordance with the Note and not later than the Maturity date provided in the Note.
2.5 Incorporation of Documents. The DEVELOPER's HOME application dated
July 8, 2013, the CITY Council approved Minutes of September 12, 2013, approving this
Agreement, the Loan Documents, the Act and HUD regulations al24 C.R.F. Part 85, 92,
CPD 98-2 and all exhibits, attachments, documents and instruments referenced herein, as
now in effect and as may be amended from time to time, constitute part of this Agreement
and are incorporated herein by reference. All such documents have been provided to the
parties herewith or have been otherwise provided to/procured by the parties and reviewed
by each of them prior to execution hereof.
2.6 Covenants of DEVELOPER, The DEVELOPER for itself and its
agents/assigns covenants and agrees to comply with all the terms and conditions of this
Agreement and the requirements of 24 CFR Part 92.
2.7 Subordination. This Agreement and the Deed of Trust may be subordinated
to certain approved financing (ín each case, a "senior Lender"), to no worse than 3td
position, but only on condition that all of the following conditions are satisfied: (a) all of the
proceeds of the proposed Senior Loan, less any transaction costs, must be used to provide
construction or permanent financing for the Project consistent with an approved financing
plan; (b) the DEVELOPER must demonstrate to the CITY's reasonable satisfaction that
subordination of Deed of Trust is necessary to secure adequate construction or permanent
financing to ensure the viability of the Project; (c) the subordination agreement must
provide the CITY with adequate rights to cure any defaults by the DEVELOPER including
providing the CITY or its successor with copies of any notices of default; (d) upon a
determination by the City Manager that the conditions in this Section have been satisfied,
the City Manager or his/her designee will be authorized to execute the approved
subordination agreement, inter-creditor agreements, standstill agreements, and/or other
documents as may be reasonably requested by the Lender to evidence subordination to
the Project financing, without the necessity of any further action or approval provided that
such agreements contain written provisions that are no more onerous and which are
consistent with the customary standard requirements imposed by the financing source(s),
on subordinate cash flow obligations under their then existing senior financing policies, and
further provided that the Gity Attorney approves such document(s) as to form.
2.8 Non-recourse. This financing is non-recourse to any public housing property
(real or personal property including all public housing assets or income), or disposition
proceeds approved pursuant to Section 18 of the United States Housing Act of 1937
(unless explicitly permitted by HUD in the Section 18 approval letter).
I
ARTICLE 3. REPRESENTATIONS AND WARRANTIES OF DEVELOPER
3.1 Existence and Qualification. The DEVELOPER, represents and warrants to
the CITY as of the date hereof, that the DEVELOPER is a duly organized California
corporation in good standing with the State of California; the DEVELOPER has the
requisite power, right, and legal authority to execute, deliver, and perform its obligations
under the HOME Agreement has taken all actions necessary to authorize the execution,
delivery, performance, and observance of its obligations under this Agreement. This
Agreement, when executed and delivered by the DEVELOPER enforceable against the
DEVELOPER in accordance with its respective terms, except as such enforceability maybe limited by: (a) bankruptcy, insolvency, fraudulent conveyance, reorganization,
moratorium, or other similar laws of general applicability affecting the enforcement of
creditors' rights generally, and (b) the application of general principles of equity without the
joinder of any other party.
3.2 No Litiqation Material to Financial Condition. The DEVELOPER represents
and warrants to the CITY as of the date hereof that, except as disclosed to and approved
by CITY in writing, no litigation or administrative proceeding before any court or
governmental body or agency is now pending, nor, to the best of the DEVELOPER's
knowledge, is any such litigation or proceeding now threatened, or anticipated against the
DEVELOPER that, if adversely determined, would have a material adverse effect on the
financial condition, business, or assets of the DEVELOPER or on the operation of the
Project.
3.3 No Conflict of lnterest. The DEVELOPER represents and warrants to the
CITY as of the date hereof that no officer, agent, or employee of the CITY directly or
indirectly owns or controls any interest in the DEVELOPER, and no person, directly or
indirectly owning or controlling any interest in the DEVELOPER, is an official, officer, agent,
or employee of the CITY.
3.4 No Leoal Bar. The DEVELOPER represents and warrants to the CITY, as of
the date hereof that the execution, delivery, performance, or observance by the
DEVELOPER of this Agreement will not, to the best of the DEVELOPER's knowledge,
materially violate or contravene any provisions of: (a) any existing law or regulation, or any
order of decree of any court, governmental authority, bureau, or agency; (b) governing
documents and instruments of the DEVELOPER; or (c) any mortgage, indenture, security
agreement, contract, undertaking, or other agreement or instrument to which the
DEVELOPER is a party or that is binding on any of its properties or assets, the result of
which would materially or substantially impair the DEVELOPER's ability to perform and
discharge its obligations or its ability to complete the Project under this Agreement.
3.5 No Violation of Law. The DEVELOPER represents and warrants to the CITY
as of the date hereof that, to the best of the DEVELOPER's knowledge, this Agreement
and the operation of the Project as contemplated by the DEVELOPER, do not violate any
existing federal, state or local laws of regulations.
3.6 No Litiqation Material to Project. The DEVELOPER represents and warrants
to the CITY as of the date hereof, except as disclosed to, and approved by the CITY in
writing, there is no action, proceeding, or investigation now pending, or any basis therefor
known or believed to exist by the DEVELOPER that questions the validity of this
Agreement, or of any action to be taken under this Agreement, that would, if adversely
determined, materially or substantially impair the DEVELOPER's ability to perform anð
observe its obLigations under this Agreement, or that would either directly or indirecily have
an adverse effect or impair the completion of the Project.
3.7 Assurance of Governmental Approvals and Licenses. The DEVELOPER
represents and warrants to the CITY, as of the date hereof, that the DEVELOPER has
obtained and, to the best of the DEVELOPER's knowledge, is in compliance with all
federal, state, and local governmental reviews, consents, authorizations, approvals, and
licenses presently required by law to be obtained by the DEVELOPER for the Project as of
the date hereof.
ARTICLE 4. COVENANTS OF THE DEVELOPER
The DEVELOPER, for itself and its development team represents and warrants that:
4.1 Accessibilitv. The DEVELOPER covenants and agrees with the CITY that it
shall comply with 24 C.F.R. Par 8, which implements Section 504 of the Rehabilitation Act
of 1973 (29 U.S.C .794), including, without limitation, the construction of the Project so thatit meets the applicable accessibility requirements, including, but not limited to, the
following:A. At least five percent (5%) of the dwelling units, or at least eight (8),
whichever is greater, must be constructed to be accessible for persons with moOìlity
disabilities. An additionaltwo percent (2%) of the dwelling units, or at least three (ã) units,
whichever is greater, must be accessible for persons with hearing or visual disabilities.
These units must be constructed in accordance with the Uniform FederalAccessibility
Standards (U.F.A.S.) or a standard that is equivalent or stricter. These mandates cañ be
found at24 C.F.R. Part 8, which implements Section 504 of the Rehabilitation Act of 1g73
(2e u.s.c.794).
B. Title lll of the Americans with Disabilíty Act of 1990 (ADA) as it relates
to the required accessibility of public and common use areas of the Project.
4.2 Affirmalive Marketinq. The DEVELOPER warrants, covenants and agrees
with the CITY that it shall comply with all affirmative marketing requirements, including
without limitation, those set out at 24 C.F.R. 92.350 and g2.351, in order to providè
information and otherwise attract eligible persons from all racial, ethnic and gender groups
in the housing market in the sale of the Project Unit. The DEVELOPER snãll Oe
responsible for complying with the CITY's "Affirmative Marketing Policy" document, as
amended from time to time. The DEVELOPER shall maintain records of actions taken to
affirmatively market units constructed in the future, and to assess the results of these
actions.
4.3 Availabilitv of HOME Funds. The DEVELOPER understands and agrees that
the availability of HOME Funds Ís subject to the control of HUD, or other federalãgencies,
and should said Funds be encumbered, withdrawn or otherwise made unavailable to the
CITY, whether earned by or promised to the DEVELOPER, and/or should the ClTy in any
fiscal year hereunder fail to allocate said Funds, the Clry shall not provide said Fundð
10
unless and until they are made available for payment to the CITY by HUD and the ClTy
receives and allocates said Funds. No other funds owned or controlled by the ClTy shall
be obligated under this Agreement to the Project.
4.4 Compliance with Aoreement. The DEVELOPER warrants, covenants and
agrees with the CITY that, in accordance with the requirements o124 C.F.R. g2.2S2 and 24
C.F.R. Part 85, upon any uncured default by the DEVELOPER within the meaning of Article
10.1 of this Agreement, the CITY may suspend or terminate this Agreement and all other
agreements with the DEVELOPER without waiver or limitation of rights/remedies othenruise
available to the CITY.
4.5 Conflict of Interest. The DEVELOPER warrants, covenants and agrees with
the CITY that it shall comply with the Conflict of lnterest requirements of 24 C.F.R. 92.356
including, without limitation, that no officer, employee, agent or consultant of the
DEVELOPER may occupy a Project Unit. The DEVELOPER understands and
acknowledges that no employee, agent, consultant, officer or elected official or appointed
official of the CITY, who exercises any functions or responsibilities with respect to the
Project, or who is in a position to participate in a decision making process or gain inside
information with regard to these activities, may obtain a financial interest or beneÍit from the
Project, or have an interest in any contract, subcontract or agreement with respect thereto,
or the proceeds thereunder, either for him or herself or for anyone with which that person
has family or business ties, during his or her tenure or for one year thereafter. To the
extent provided al24 C.F.R. 92.356(0, no owner, developer or sponsor of the Project, or
officer, employee, agent or consultant thereof, may occupy a project unit.
4.6 Construction Standards. The DEVELOPER shall rehabilitate the proposed
Project Unit assisted under this Agreement in compliance with all applicable local codes,
ordinances and zoning requirements in effect at the time of issuance of ClTy building
permits.
4.7 Covenants and Restrictions to Run with the Land. The CITY and the
DEVELOPER expressly warrant, covenant and agree to ensure that the covenants and
restrictions set forth in this Agreement are recorded and will run with the land, provided,
however, that, on expiration of this Agreement such covenants and restrictions shall expire,
provided that such agreements contain written provisions that are no more onerous and
which are consistent with the customary standard requirements imposed by the financing
source(s), on subordinate cash flow obligations under their then existing senior financing
policies, and further provided that the City Attorney approves such document(s) as to form.
A. The CITY and the DEVELOPER hereby declare their understanding
and intent that the covenants and restrictions set forth herein directly benefit the land (a) by
enhancing and increasing the enjoyment and ownership of the proposed Project by a
certain Low-lncome Household, and (b) by making possible the obtaining of advantageóus
financing for the rehabilitation.
B. The DEVELOPER covenants and agrees with the CITY that after
issuance of a recorded Certification of Completion for the Project until the expiration of the
Affordability Period it shall cause the nine (9) Project Units to be rented as HOME-assisted
Affordable Housing to Low-lncome Households.
11
C. Without waiver or limitation, the CITY shall be entitled to injunctive or
other equitable relief against any violation or attempted violation of any covenants and
restrictions, and shall, in addition, be entitled to damages available under law or contract
for any injuries or losses resulting from any violations thereof.
D. All present and future owners of the Propefi and other persons
claiming by, through, or under them shall be subject to and shall comply with the covenants
and restrictions. The acceptance of a deed of conveyance to the Property shall constitute
an agreement that the covenants and restrictions, as may be amended or supplemented
from time to time, are accepted and ratified by such future owners, tenant or occupant, and
all such covenants and restrictions shall be covenants running with the land and shall bind
any person having at any time any interest or estate in the Property, all as though such
covenants and restrictions were recited and stipulated at length in each and every deed,
conveyance, mortgage or lease thereof.
E. The failure or delay at any time of the CITY or any other person
entitled to enforce any such covenants or restrictions shall in no event be deemed a waiver
of the same, or of the right to enforce the same at any time or from time to time thereafter,
or an estoppel against the enforcement thereof.
4.8 Displacement of Persons. The DEVELOPER covenants and agrees with the
CITY that pursuant to 24 C.F.R. 92.353, it will take all reasonable steps to minimize the
displacement of any persons (families, individuals, businesses, nonprofit organizations and
farms). The parties acknowledge and agree that the Property is currently occupied with
tenants.
4.9 lnitial and Annual lncome Certification and Reportinq. The DEVELOPER
covenants and agrees that it shall comply with the procedures for income determinations at
24 C.F.R. 92.203 for the nine (9) HOME-assisted units. The DEVELOPER, shall obtain,
complete and maintain on file, immediately prior to initial occupancy, and annually
thereafter, income certifications from each tenant Household renting any HOME-assisted
Unit. The DEVELOPER, shall make a good faith effort to verify that the income provided
by an applicant or occupying Household in an income certification is accurate by taking one
or more of the following steps as part of the verification process: (1) obtain a pay stub for
the most recent pay period; (2) obtain an income verification form from the applicant's
current employer; (3) obtain an income verification form from the Social Security
Administration and California Department of Social Services if the applicant receives
assistance from either of such agencies; (4) obtain income tax return for the most recent
tax year; or (5) if the applicant is unemployed, obtain another form of independent
verification. Copies of Household income certification and verification must be available for
review and approval by the CITY. The DEVELOPER further warrants, covenants and
agrees that it cooperate with the CITY in the CITY's income certification/affordability
monitoring activities.
4.10 Lead-Based Paint. The DEVELOPER covenants and agrees with the CITY
that it shall comply with all applicable requirements of the Lead-Based Paint Poisoning
Prevention Act of 42 U.S.C. 4821 et seq.,24 C.F.R. Part 35, including the HUD 1012 Rule,
and 24 C.F.R. 982.401O, and any amendment thereto, and Environmental Protection
Agency (EPA) Section 402 (c)(3) of the Toxic Substances Control Act (TSCA) to address
12
lead-based hazards created by renovation, repair, and painting activities that disturb lead-
based paint in target housing and child-occupied facilities. Contractors performing
renovations in lead-based paint units must be EPA-certifíed renovators. These
requirements apply to all units and common areas of the Project. The DEVELOPER shall
incorporate or cause incorporation of this provision in all contracts and subcontracts for
work performed on the Project, which involve the application of paint. The DEVELOPER
shall be responsible for all disclosure, inspection, testing, evaluation, and control and
abatement activities.
4.11 Minority Outreach Activities. The DEVELOPER covenants and agrees with
the CITY that it shall comply with all federal laws and regulations described in Subpart H of
24 C.F.R. Part 92, including, without limitation, any requirement that the DEVELOPER
comply with the CITY's minority outreach program.
4.12 Other Laws and Requlations. The DEVELOPER covenants and agrees with
the CITY that, in addition to complying with the federal laws and regulations already cited in
this Agreement, the DEVELOPER has reviewed, and shall comply with and require all its
contractors and subcontractors on the Project to comply with, all other federal laws and
regulations that apply to the HOME Program, including, without limitation, requirements of
24 C.F.R. 58.6 and the Flood Disaster Protection Act of 1973, as amended (42 U.S.C.
4001 4128 the following :
A. The DEVELOPER does not intend to use any financing that is secured
by a mortgage insured by HUD in connection with the Project as part of its rehabilitation
costs of the Project.
B. The Project is not located in a tract identified by the Federal
Emergency Management Agency as having specialflood requirements.
C. The Project requirements, Subpart F of 24 C.F.R. Part 92, as
applicable and in accordance with the type of Project assisted, including, but not limited to,
the HOME per-unit subsidy amount at24 C.F.R. 92.250.
D. The property standards at 24 CFR 92.251.
E. The Project "Labor" requirements, as applicable, of 24 C.F.R. 92.354
including Davis Bacon prevailing wage requirements (40 U.S.C. 276a - 276a-7), as
supplemented by Department of Labor regulations (29 CFR Part 5).
F. The provisions of Section 102 and 107 of the Contract Work Hours and
Safety Standards Act (40 U.S.C. 327-333), as supplemented by Department of Labor
Regulations (29 CFR Part 5), in regards to the construction and management of the
proposed Project.
G. The DEVELOPER and its contractors, subcontractors and service
providers for the Project, shall comply with all applicable local, State and federal
requirements concerníng equal employment opportunity, including compliance with
Executive Order (E.O.) 11246, "Equal Employment Opportunity", as amended by E.O.
11375, (amending E.O. 11246 Relating to Equal Employment Opportunity), and as
13
supplemented by regulations at 41 C.F.R. part 60, "Office of Federal Contract Compliance
Programs, Equal Employment Opportunity, Department of Labor".
H. The provisions of the Copeland "Anti-Kickback" Act (18 U.S.C. 874), as
supplemented by Department of Labor regulations (29 C.F.R. part 3, "Contractors and
Subcontractors on Public Building or Public Work Financed in Whole or in Part by Loans or
Grants from the United States").
l. The provisions of the Clean Air Act (42 U.S.C.7401 et seq.) and the
Federalwater Pollution ControlAct (33 u.s.c. 1251 elseq.), as amended.
J. The provisions of the Byrd Anti-Lobbying Amendment (31 U.S.C.
1352).
K. The provision of E.O.s 12549 and 12689, "Debarment and
Suspension," as set forth at24 C.F.R. part24.
L. The provisions of the Drug-Free Workplace Act of 1988 (42 U.S.C.
701), in accordance with the Act and with HUD's rules at 24 CFR part24, subpart F.
M. Title I of the Civil Rights Act of 1968 PL. 90-284.
N. E.O. 1 1063 on Equal Opportunity and Housing.
O. Section 3 of the Housing and Urban Development Act of 1968
P. The Housing and Community Development Act of 1974.
O. Clean Water Requirements 33 U.S.C. 1251.
R. Civil Rights Requirements, 29 U.S.C. 623, 42 U.S.C. 2000, 42 U.S.C.
6102,42 U.S.C 12112,42 U.S.C. 12132,49 U.S.C 5332,29 C.F.R. Part 1630,41 C.F.R.
and Part 60 et seq.
4.13 Faith Based Activities. The DEVELOPER warrants, covenants and agrees
with the CITY that it shall not engage in any prohibited activities described in 24 C-.F.R.
92.257.
4.14 Reportino Requirements. The DEVELOPER warrants, covenants and agrees
with the CITY that it shall submit performance reports to the CITY as detailed in Section7.17. Furthermore, the DEVELOPER agrees to provide, at the sole cost of the
DEVELOPER, an annual audited Financial Statements for the Project expenses and
ongoing financial transactions which occur as a result of this Agreement as detailed in
Section 5.6. The DEVELOPER agrees to account for the expenditure of HOME Funds
using generally accepted accounting principles, which financial documentation shail be
made available to the CITY and HUD upon their respective written request(s).
4.15 Affordabilitv Period. The DEVELOPER covenants and agrees with the ClTy
that the nine (9) of the Project Units will be Affordable Housing available to a Low-lncome
14
Household and other requirements of 24 C.F.R. 92.252 during the Atfordability Period. Two
(2) Units, at a minimum, will be rented to and occupied by, or if vacant, available for rent
and occupancy by (a) person(s) whose annual household income at the time of initial
occupancy is not greater than fifty percent (50%), and seven (7) Units shall, at a minimum,
be rented to and occupied by or, if vacant available for rent and occupancy by (a) person(s)
whose annual household income at the time of initial occupancy is not greater than eighty
(80%) of the most recent annual median income calculated and published HUD for the
Fresno Metropolitan Statistical Area applicable to such household's size, and at an
affordable rent consistent with the HOME Program regulations, for the Affordability period
except upon foreclosure or other transfer in lieu of foreclosure following default under a
Deed of Trust. However, if at any time following a transfer by foreclosure or transfer in lieu
of foreclosure or transfer in lieu of foreclosure, but still during the Affordability Period, the
owner of record prior to the foreclosure or transfer in lieu of foreclosure, or any newly
formed entity that includes such owner of record those whom such owner of record has or
had business ties, obtained an ownership interest in the Project or the Property, the
Affordability Period shall be revived according to its original terms. ln the event
DEVELOPER fails to comply with this section or the Affordability Period is not revived
following transfer by foreclosure or transfer in lieu of foreclosure, the DEVELOPER shall
return to the CITY allthe HOME Funds disbursed to the DEVELOPER by the C|TY.
4.16 Terminated Projects. The DEVELOPER understands and agrees that, if the
Project is terminated before completion, either voluntarily or othenruise, such constitutes an
ineligible activity and the Clry will not be required to provide any further HOME Program
assistance funding to the Project and the CITY may seek available relief.
ARTICLE 5. PROPERW MAINTENANCE
The DEVELOPER covenants and agrees to the following, for the entire term of the
Agreement.
5.1 Adequate Repair and Maintenance. After rehabilitation of the Project, the
DEVELOPER shall cause the maintenance the Project and Property to be in compliance
with all applicable codes, laws, and ordinances.
5.2 Affordable Rental Housinq. The DEVELOPER covenants and agrees that the
Affordable Project shall constitute nine (9) affordable rental Units preserved as floating
Low-lncome Rental Housing (as provided at 24 C.F.R.92.252) during the fifty-five (5S) yeai
affordability period. ln the event the DEVELOPER fails to comply with the time period in
which the Affordable Units constitute Affordable Housing, the CITY shall without waiver or
limitation, be entitled to injunctive relief, as the DEVELOPER acknowledges that the
damages are not adequate remedy at law for such breach,
5.3 Compliance with Environmental Laws. The DEVELOPER shall cause the
Affordable Units to be in compliance with, and not to cause or permit the Project to be in
violation of, any Hazardous Materials law, rule, regulation, ordinance, or statute. Although
the CITY will utilize its employees and agents for regular inspection and testing of tñe
eligible Property, the DEVELOPER agrees that, if the CITY has reasonable grounds to
suspect any such violation, the DEVELOPER shall be entitled to thirty (30) days' notice and
opportunity to cure such violation. lf the suspected violation is not cured, the ClTy shall
15
have the right to retain an independent consultant to inspect and test the eligible property
for such violation. lf a violation is discovered, the DEVELOPER shatf pay foi tne
reasonable cost of the independent consultant.
Additionally, the DEVELOPER agrees:
A. That the CITY shall not be directly or indirectly responsible, obligated
or liable with the inspection, testing, removal or abatement of asbestos or other hazaidous
or toxic chemicals, materials, substances, or wastes and that all cost, expense and liability
for such work shall be and remain solely with the DEVELOpER;
B. Not to transport to, or from, the proposed Property, or use, generate,
manufacture, produce, store, release, discharge, or dispose of on, under, or ãbout the
Property, or surrounding real estate, or transport to or from the project site, or surrounding
real estate, any hazardous or toxic chemicals, materials, substance, or wastes or allow any
person or entity to do so except in such amounts and under such terms and conditions
permitted by applicable laws, rules, regulations, ordinances, and statutes;
C. To give prompt written notice to the CITY of the following:
1. Any proceeding or inquiry by any governmental authority with
respect to the presence of any hazardous or toxic chemicals, materials, substanôe, or
waste in or on the eligible Property or the surrounding real estate or the migration thereof
from or to other property; and
2. All claims made or threatened by any third party against theDEVELOPER, or such properties relating to any loss or irijury resulting -from any
hazardous or toxic chemicals, materials, substance, or waste; and
3. The DEVELOPER's discovery of any occurrence or condition on
any real property adjoining or in the vicinity of such properties that would cause suchproperties or underlying or surrounding real estate or part thereof to be subject to any
restrictions on the ownership, occupancy, transferability, or use of the property under any
environmental law, rule, regulation, ordinance or statute; and
4. To jndemnify, defend, and hold the clry harmless from any and
all claims, actions, causes of action, demand, judgments, damages, injuries, administiative
orders, consent agreements, orders, liabilities, penalties, cósts, êxpenses (including
attorney's fees and expenses), and disputes of any kind whatsoever arising òut of or
relating to the DEVELOPER or any other par y's use of release of any hazardıus or toxic
chemicals, materials, substance, or waste on the Property regardbsð of cause or origin,
including any and all liability arising out of or relating to any investigation, site monitoring,
containment, cleanup, removal, restoration, or related remedial workôf any kind or naturel
5.4 Compliance With Laws. The DEVELOPER shall promptly and faithfully
comply with, conform to and obey all present and future federal, state anâ local statutes,
regulations, rules, ordinances and other legal requirements applicable by reason of thisAgreement or otherwise to the Project including without 'limitation
prevailing wagerequirements. The DEVELOPER acknowledges that the use of HOME Funds subjécts tñe
16
Project to extensive federal regulation and covenants and agrees that it shall comply with,
conform to and obey (and take steps as are required of the DEVELOPER to enable the
CITY to comply with, conform to and obey) all federal statues, regulations, rules and
policies applicable to the Project.
5.5 Existence. Qualification, and Authority. The DEVELOPER shall provide to
the CITY any evidence required or requested by the CITY to demonstrate the continuing
existence, qualification, and authority of the DEVELOPER to execute this Agreement and
to perform the acts necessary to carry out the Project.
5.6 Financial Statements and Audits. The DEVELOPER, as a subrecipient of
federal financial assistance, is required to comply with the provisions of the Single Audit Act
of 1984 (31 U.S.C. Sections 7501 et seq.), as amended. Annually, within one hundred and
eighty (180) days following: 1) the end of fiscal yea(s) in which the HOME Funds are
disbursed hereunder, and 2) the end of fiscal yea(s) in which this contract shall terminate,
and otherwise upon the CITY's, written request during the term of this Agreement, the
DEVELOPER, at its sole cost and expense shall submit to the CITY:
A. Audited annual financial statements that are current, signed, and
prepared according to generally accepted accounting principles consistently applied
(except as othen¡vise disclosed therein).
B. Audited Financial Statements covering the income and expenses, and
the financialtransactÍons for the Project during the prior fiscal year.
5.7 lnspection and Audit of Books, Records and Documents. The DEVELOPER
shall be accountable to the CITY for all HOME Funds disbursed for the Project pursuant to
this Agreement. Any duly authorized representative of the CITY or HUD shall, at all
reasonable times, have access to and the right to inspect, copy, make excerpts or
transcripts, audit, and examine all books of accounts, records, files and other papers or
property, and other documents of the DEVELOPER pertaining to the Project or all matters
covered in this Agreement and for up to six (6) years after the expiration or termination of
this Agreement.
A. The DEVELOPER will maintain books and records for the Project
using generally accepted accounting principles. The DEVELOPER agrees to maintain
books and records that accurately and fully show the date, amount, purpose and payee of
all expenditures fïnanced with HOME Funds and to keep all invoices, receipts and other
documents related to expenditures financed with HOME Funds for not less than six (6)
years after the expiration or termination of the Agreement. Books and records must be
kept accurate and current. For purposes of this section, "books, records and documents"
include, without limitation; plans, drawings, specifications, ledgers, journals, statements,
contracts/agreements, funding information, funding applications, purchase orders,
invoices, loan documents, computer printouts, correspondence, memoranda, and
electronically stored versions of the foregoing. This section shall survive the termination of
this Agreement.
B. The CITY may audit any conditions relating to this Agreement at the
CITY's expense, unless such audit shows a significant discrepancy in information reported
17
by the DEVELOPER in which case the DEVELOPER shall bear the cost of such audit. The
DEVELOPER shall also comply with any applicable audit requirements of 24 C.F.R.
92.506. This section shall survive the termination of this Agreement.
C. The DEVELOPER will cooperate fully with the CITY and HUD in
connection with any interim or final audit relating to the Project that may be performed
relative to the performance of this Agreement.
5.8 Inspection of Propertv. Any duly authorized representative of the CITY or
HUD shall, at all reasonable times, have access and the right to inspect the Property until
completion of the Project and expiration of the applicable Affordability Period within
seventy-two (72) hours' written notice, subject the rights of the tenants.
5.9 No Other Liens. The DEVELOPER shall not create or incur, or suffer to be
created or incurred, or to exist, any additional mortgage, pledge, encumbrance, lien,
charge, or other security interest of any kind on the eligible Property, other than those
related to the Project's construction or pre-development loans in relation to the Project,
consistent with the attached Budget, without the prior written consent of the CITY.
5.10 Nondiscrimination. The DEVELOPER shall comply with and cause any and
all contractors and subcontractors to comply with any and all federal, state, and local laws
with regard to illegal discrimination, and the DEVELOPER shal! not illegally discriminate
against any persons on account of race, religion, sex, family status, age, handicap, or place
of national origin in its performance of this Agreement and the completion of the Project.
5.11 Ownership. Except as required in pursuit hereof, the DEVELOPER shall not
sell, lease, transfer, assign or othenruise dispose ("Transfer") all or any material part of any
interest it might hold in the Property or the Project without the prior wriüen consent of the
CITY, which consent shall not be unreasonably withheld or delayed. Transfer shall exclude
the leasing of any single Unit in the Project.
A. The DEVELOPER shall request the City's written approval of the granting
of the securing interest in the Property described in Section 5.9 above.
B. The DEVELOPER anticipates syndicating the low income housing tax
credits that will be generated by the Project, which syndication will require the transfer of
limited partnership interests. The CITY hereby approves the initial Transfer of the limited
partner interest to affiliates of the investor, provided that in each instance the CITY is given
prior written notice.
5.12 Pavment of Liabilities. The DEVELOPER shall pay and discharge in the
ordinary course of its business all material obligations and liabilities, the nonpayment of
which could have a material or adverse impact on its financial condition, business, or
assets or on the operation of the Project, except such obligations and liabilities that have
been disclosed to the CITY in writing and are being contested in good faith.
5.13 Report of Events of Default. The DEVELOPER shall promptly give written
notice to the CITY upon becoming aware of any Event of Default under this Agreement.
18
ARTICLE 6. DISBURSEMENT OF HOME FUNDS
Without waiver of limitation, the parties agree as follows, regarding HOME Funds:
6.1 Loan Commitments and Financino Plan. The DEVELOPER shall submit its
most current Finance Plan for the Project to the CITY within the time frame provided in the
Project Schedule. So long as the Finance Plan is consistent with the Budget, the CITY
shall accept the Finance Plan. lf the FÍnance PIan is not consistent with the Budget, then
within thirty (30) days after receiving the Finance Plan, the CITY through its Development
and Resource Management Department, Housing and Community Development Division,
will review the Finance Plan and deliver notice to the DEVELOPER either approving or
disapproving the Finance Plan in its reasonable discretion. lf the CITY disapproves the
Finance Plan, it will specify the reason for the disapproval and ask the DEVELOPER to
provide any additional information the CITY may need to approve the Finance Plan. The
failure of the CITY to send notice within such thirty (30) day time period shall be deemed an
approval of the Finance Plan.
6.2 Use of HOME Funds. The DEVELOPER warrants, covenants and agrees
with the CITY that it shall request HOME Funds only for reimbursement of eligible costs
incurred as identified in the attached Budget, attached hereto as EXHIBIT "C', including
costs allowable under 24 C.F.R. 92.206, aggregating not more than One Million Five
Hundred Thousand dollars and 00/100 ($t,500,000.00). The CITY's obligation shall in no
event exceed the HOME Funds amount specified in this Agreement.
A. lf any such Funds shall be determined to have been requested and/or
used by the DEVELOPER for costs other than for eligible rehabilitation reimbursement
costs, and subject to the notice and cure provisions of Section 10.2 hereunder, an equal
amount from non-public funds shall become immediately due and payable by the
DEVELOPER to the CITY; provided, however, that the DEVELOPER shall, subject to its
full cooperation with the CITY, be entitled to participate in any opportunity to remedy,
contest, or appeal such determination.
B. ln the event HOME Funds are requested to reimburse Eligible Costs
which subsequently lose eligibility as Eligible Costs, the DEVELOPER shall immediately
return such HOME Funds to the CITY.
C. The GITY will disburse HOME Funds, only to the DEVELOPER
through proper invoicing costs of the Project as provided in this Article 6.
6.3 Conditions Precedent to Disbursement. The CITY shall not be obligated to
make or authorize any disbursements of HOME Funds unless the following conditions are
satisfied:
A. There exists no Event of Default as provided in Article 10, nor any act,
failure, omission or condition that with the passage of time or the giving of notice or both
would constitute an Event of Default.
B. The DEVELOPER has submitted the Finance Plan to the CITY, and if
requíred, the CITY has approved the Finance Plan.
19
C. The CITY has approved the requested reimbursement of eligible
Project costs.
D. The DEVELOPER has obtained insurance coverage and delivered to
the City evidence of insurance as required in Article 9.
E. The DEVELOPER is current with its compliance of reporting
requirements set forth in this Agreement.
F. The DEVELOPER has provided the CITY with a written request for
HOME Funds (provided by the CITY), for reimbursement of etigible Project costs, and
detailing such Eligible Costs applicable to the request.
G. The CITY has received certification required by Section 6.5 of this
Agreement.
H. The CITY has received, and continues to the have the right to
disburse, HOME Funds.
6.4 Requests for Disbursement of HOME Funds. The DEVELOPER shall
reguest reimbursement of HOME Funds using the CITY's Request for Reimbursement of
Funds form. The DEVELOPER shall only request a maximum of One Million Five Hundred
Thousand dollars and 00/100 ($t,500,000.00) in HOME Program assistance for project
rehabilitation costs. All requests for HOME Funds reimbursement shall be accompanied
with the Certification required by Section 6.6 of this Agreement and demonstrate they are in
compliance with the requirements set forth in CPD 98.2 for'Tloating" Units.
6.5 DEVELOPER Certification. The DEVELOPER shall submit to the CITY a
written certification that, as of the date of the Request for Reimbursement ("Certification"):
A. The representations and warranties contained in or incorporated by
reference in this Agreement continue to be true, complete and accurate in material
respects;B. The DEVELOPER has carried out all of its obligations and is in
compliance with all the obligations or covenants specified in this Agreement, to the extent
that such obligations or covenants are required to have been carried out or are applicable
at the time of the request for the Reimbursement;
C. The DEVELOPER has not committed or suffered an act, event,
occurrence, or circumstance that constitutes an Event of Default or that with the passage of
time or giving of notice or both would constitute an Event of Default; and
D. The Disbursement requested will be used solely for reimbursement of
Eligible Costs identified in this Agreement and must by supported by the itemized
obligations that have been properly incurred and are properly chargeable in connection
with the Project.
6.6 Disbursement of Funds. The disbursement of HOME Program Loan Funds
20
shall occur within the normal course of CITY business (approximately thirty (30) days) after
the CITY receives the Certification and to the extent of annually allocated and availabte
HOME Funds.
ARTICLE 7. REHABILITATION OF PROJECT
Without waiver of limitation, the parties agree as follows:
7.1 Meetinq Reoardino HOME Prooram Processes and Procedures. The CITY
will schedule, and the DEVELOPER shall attend a meeting prior to rehabilitation with the
clrY for the purpose of outlining the Project processes and procedures.
7.2 Commencement and Completion of Proiect. The DEVELOPER shall
commence rehabilitation of the Project and, record a Notice of Completion of construction
of the Project in accordance with the Project Schedule as identified in EXHIBIT'8".
7.3 Contracts and Subcontracts. Consistent with Section 5.3, all hazardous
waste abatement, construction work and professional services for the Project shall be
performed by persons or entities licensed or othenrise legally authorized to perform the
applicable work or service in the State of California and the City of Fresno. The
DEVELOPER shall provide the CITY with copies of all agreements it has entered into with
any and all general contractors or subcontractors for this Project. The DEVELOPER shall
require that each such general contractor agreement contain a provision whereby the
party(ies) to the agreement, other than the DEVELOPER, agree to: (i) notify the CITY
immediately of any event of default by the DEVELOPER thereunder, (ii) notify the ClTy
immediately of the filing of a mechanic's lien, (iii) notify the CITY immediately of termination
or cancellation of the construction agreement on the Project, and (iv) provide the CITY,
upon the CITY's request, an Estoppel Certificate certifying that the agreement is in full
force and effect and the DEVELOPER is not in default thereunder. The DEVELOPER
agrees to notify the CITY immediately of termination or cancellation of any such
agreement(s), notice of filing of a mechanic's lien, or breach or default by other party(ies)
thereto.
7.4 Damaoe to Property. To the extent consistent with the requirements of any
permitted encumbrance, or as othenryise approved by the CITY, and subject to Article g of
this Agreement, if any building or improvement constructed on the Property is damaged or
destroyed by an insurable cause, the DEVELOPER shall, at its cost and expense, diligenfly
undertake to repair or restore said buildings and improvements consistent with the original
Plans and Specifications of the Project. Such work or repair within ninety (90) days after
the insurance proceeds are made available to the DEVELOPER and shall be completed
within two (2) years thereafter. All insurance proceeds collected for such damage or
destruction shall be applied to the cost of such repairs or restoration and, if such insurance
proceeds shall be insufficient for such purpose, the DEVELOPER shall use its best efforts
to make up the deficiency.
7.5 Fees. Taxes and Other Levies. The DEVELOPER shall be responsible for
payment of all fees, assessments, taxes, charges and levies imposed by any public
authority or utility company with respect to the Property or the Project, and shall pay such
charges prior to delinquency. However, the DEVELOPER shall not be required to pay and
21
discharge any such charge so long as: (a) the legality thereof is being contested diligently
and in good faith and by appropriate proceedings, and (b) if requested by the CITY, the
DEVELOPER deposits with the CITY any funds or other forms of assurances that the
CITY, in good faith, may determine from time to time are appropriate to protect the CITY
from the consequences of the contest being unsuccessful. The DEVELOPER shall have
the right to apply for and obtain an abatement and/or exemption of the Project from real
property taxes in accordance with all applicable rules and regulations, including Section
21a@) of the California Revenue and Taxation Code.
7.6 Financino. The DEVELOPER shall promptly inform the CITY of any new
financing or funding not included in the Budget for the Project, and the DEVELOPER shall
provide the CITY with copies of all agreements with any and all funding sources for the
Project. The DEVELOPER shall require each agreement with any and all funding sources
not included in the Budget to contain a provision whereby the party(ies) to the agreement
other than the DEVELOPER, ¡f permitted by the party(ies) applicable rules and regulations,
agree to notify the CITY immediately of any event of default by the DEVELOPER
thereunder. Should the DEVELOPER not comply with all the obligations of this section, the
loan shall become immediately due and payable as provided for in this Agreement. This
Section shall survive expiration or termination of this Agreement.
7.7 ldentification Sionaqe. Before the start of rehabilitation, the DEVELOPER
shall place a poster or sign, with a minimum four feet by four feet in size, identifying the
City of Fresno Development and Resource Management Department, Housing and
Community Development Division as a Project participant. The sign shall also include the
CITY's Housing logo, as well as the Equal Housing Opportunity logo, as mandated by
HUD. The font size shall be a minimum of 4 inches. The poster/sign shall be appropriately
place, and shall remain in place throughout the Project construction.
7.8 lnspections. The DEVELOPER shall permit, facilitate, and require its
contractors and consultants to permit and facilitate observation and inspection at the job
site by the CITY and other public authorities during reasonable business hours, for the
purpose of determining compliance with this Agreement, including without limitation those
annual on-site inspections required of the CITY by 24 C.F.R. 92.504(d).
7.9 Utilities. The DEVELOPER shall be responsible, at its sole cost and
expense, to determine the location of any utilities on the Property and to negotiate with the
utility companies for, and to, relocate the utilities, if any, as necessary to complete the
Project.
7.10 lnsurance and Bonds. The DEVELOPER shall submit for CITY approval
bonds, certificates and applicable endorsements for all insurance and bonds required by
this Agreement in accordance with Article 9.
7.11 Mechanic's Liens and Stop Notices. lf any claim of lien is filed against the
Property or a stop notice affecting any fínancing, HOME Program Funds or funding sources
for the Project is served on the CITY or any other third party in connection with the Project,
the DEVELOPER shall, within twenty (20) days of such filing or service, either pay and fully
discharge the lien or stop notice, effect the release of such lien or stop notice by delivering
to the CITY a surety bond in sufficient form and amount, or provide the CITY with other
22
assurance satisfactory to the CITY that the claim of lien or stop notice will be paid or
discharged.
A. lf the DEVELOPER fails to discharge, bond or othenruise satisfy the
C|TY with respect to any lien, encumbrance, charge or claÍm referred to in Section 7.11
above, then, in addition to any other right or remedy, the CITY may, but shall not be
obligated to, discharge such lien, encumbrance, charge, or claim at the DEVELOpER's
expense. Alternatively, the CITY may require the DEVELOPER to immediately deposit
with the CITY, the amount necessary to satisfy such lien or claim and any costs, pending
resolution thereof. The CITY may use such deposit to satisfy any claim or lien that is
adversely determined against the DEVELOPER. The DEVELOPER hereby agrees to
indemnify and hold the CITY harmless from liability for such liens, encumbrances, charges
or claims together with all related costs and expenses.
7.12 Permits and Licenses. Upon the CITY's reasonable request, the
DEVELOPER shall submit, for CITY approval, all the necessary permits and licenses
required for Commencement of the rehabilitation of the Project. As the CITY may
reasonably request, the DEVELOPER, at its sole cost and expense, shall provide to the
CITY copies of any and all permit approvals and authorizations including plot plan, plat,
zoning variances, sewer, building, and other permits required by governmental authorities
other than the CITY in pursuit of the Project, and for its stated purposes in accordance with
all applicable building, environmental, ecological, landmark, subdivision, zoning codes,
laws, and regulations.
7.13 Plans and Scope of Work. Before Commencement of the rehabilitation of the
Project, the DEVELOPER shall submit to the CITY, for its review and approval, the plans
and Scope of Work for the rehabilitation work. The DEVELOPER will perform rehabilitation
of the Project in full conformance with the C|TY-approved plans and scope of work thereto
approved by the CITY. The DEVELOPER shall obtain the CITY's prior written approval for
any modifications to the plans and scope of work.
7.14 Propertv Condition. The DEVELOPER shall maintain the Project and all
improvements on site in a reasonably good condition and repair (and, as to landscaping, in
a healthy condition), all according to the basic design and related plans, as amended from
time to time. The DEVELOPER and those taking direction under the DEVELOPER shall:(¡) maintain all on-site improvements according to all other applicable law, rules,
governmental agencies and bodies having or claiming jurisdiction and all their respective
departments, bureaus, and officials; (ii) keep the improvements free from graffiti; (iii) keep
the Project Property free from any accumutation of debris or waste material; (iv) promply
make repairs and replacements to on-site improvements; and (v) promptly replace any
dead, or diseased plants and/or landscaping (if any) with comparable materials.
7.15 Qualitv of Work. The DEVELOPER shall ensure that rehabilitation of the
Project employs building materials of a quality suitable for the requirements of the Project.
The DEVELOPER shall cause completion of the rehabilitation of the Project on the
Property in full conformance with applicable local, state and federal laws, statutes,
regulations, and building and housing codes.
7.16 Relocation. lf and to the extent that the rehabilitation of the proposed Project
23
results in the permanent or temporary displacement of residential tenants, the
DEVELOPER shall comply with all applicable local, state and federal statutes and
regulations with respect to relocation planning, advisory assistance and payment of
monetary benefits. The DEVELOPER shall be solely responsible for payment of any
relocation benefits to any displaced persons and any other obligations associated with
complying with said relocation laws.
7.17 Reportino Requirements. The DEVELOPER shall submit to the CITY the
following Project reports:
A. From the date of execution of this Agreement, until issuance of the
final Certificate of Completion, the DEVELOPER shall submit a Quarterly Report, in a form
approved by the CITY, which will include, al a minimum, the following information:
progress of the Project and affirmative.marketing efforts. The Quarterly Reports are due
fifteen (15) days after each March 31't, June 30th, September 30th, and December 31't
during said period.
B. Annually, beginning on the first day of the month following the CITY's
issuance of the Certificate of Completion, and continuing until the termination of the
Agreement, the DEVELOPER shall submit an Annual Report to the CITY, in a form
approved by the CITY. The Annual Report shall include, at a minimum, the following
information: occupancy of each Project Unit including the annual income and the
household size, the date occupancy commenced, certification from an officer of the
DEVELOPER that the Project is in compliance with the Affordability requirements, and
such other information the Clry may be required by law to obtain. The DEVELOPER shall
provide any additional information reasonably requested by the CITY.
C. Annually, beginning on the first day of the month following the CITY's
issuance of the final Certificate of Completion, evidencing the rehabilitation of the Project,
and continuing until the expiration of the Agreement, the DEVELOPER shall submit proof of
insurance as required in Article 9.
7.18 tr
shall be the responsibility of the DEVELOPER to coordinate and schedule the work to be
performed so that the Commencement of the rehabilitation and issuance of the Notice of
Completion will take place in accordance with the provisions of the Agreement and Project
Schedule. The time for performance contained in the Project Schedule shall be
automatically extended upon the following:
A. The time for performance of provisions of the Agreement by either
party shall be extended for a period equal to the period of any delay directly affecting the
Project or this Agreement which is caused by: war, insurrection, strike or other labor
dísputes, lock-outs, riots, floods, earthquakes, fires, casualties, acts of God, acts of a public
enemy, epidemics, quarantine restrictions, freight embargoes, lack of transportation, suits
fïled by third parties concerning or arising out of this Agreement, or unseasonable weather
conditions ("force majeure"). An extension of time for any of the above specified causes
will be granted only if written notice by the party claiming such extension is sent to the other
party within ten (10) calendar days from the date the atfected party learns of the
commencement of the cause and the resulting delay and such extension of time is
24
accepted by the other party in writing. ln any event, the Project must be completed no later
than one hundred eighty (180) calendar days after the scheduled completion date specified
in this Agreement, notwithstanding any delay caused by that included in this section.
B. Any and all extensions hereunder shall be by mutual written
agreement of the CITY's Housing and Community Development Division Manager and the
DEVELOPER, shall not cumulatively exceed one hundred eighty (180) days.
7.19 Certificate of Completion. Upon completion of the Rehabilitation of the
Project, the DEVELOPER shall submit to the CITY: 1) certification in writing to that the
Project has been substantially rehabilitated in accordance with the plans and scope of
work, approved by the CITY; 2) a recorded Notice of Completion; 3) a cost-certifying final
budget where the DEVELOPER shall identífy the actual costs of construction of the Project.
This final cost-certification shall identify costs in line-item format, consistent wíth the Project
Budget; 4) a request for a recorded Certification of Completion. Upon a determination by
the CITY that the DEVELOPER is in compliance with all of the DEVELOPER's
rehabilitation obligations, as specified in this Agreement, the CITY shallfurnish, within thirty
(30) calendar days of a written request by the DEVELOPER, a recordable Certificate of
Completion for the Project in the form attached hereto as EXHIBIT 'Eu. The CITY will not
unreasonably withhold or delay furnishing the Certificate of Completion. lf the CITY fails to
provide the Certificate of Completion within the specified time, it shall provide the
DEVELOPER a written statement indicating in what respects the DEVELOPER has failed
to complete the Project in conformance with this Agreement or has otherwise failed to
comply with the terms of this Agreement, and what measures the DEVELOPER will need to
take or what standards it will need to meet in order to obtain the Certificate of Completion.
Upon the DEVELOPER taking the specified measures and meeting the specified
standards, the DEVELOPER will certify to the CITY in writing of such compliance and the
CITY shall deliver the recordable Certificate of Completion to the DEVELOPER in
accordance with the provisions of this section.
ARTICLE 8. OPERATIONS OF THE PROJECT
8.1 Operation of the Proiect. The DEVELOPER shall lease operate and/or
manage the Project in full conformity with the terms of this Agreement.
8.2 Occupancv Requirements. Two (2) of the HOME-assisted Affordable Units
shall be rented and occupied by, or if vacant, available for rental occupancy by those
whose annual household income a the time of initial occupancy is not greater than fifty
percent (50%) of the most recent annual median income, calculated and published by HUD
for the Fresno Metropolitan Statistical Area, applicable to such household's size, and at an
affordable rent consistent with the HOME Program regulations (as provided at 24 C.F.R.
92.252) for the term of this Agreement. Seven (7) if the HOME-assÍsted Affordable Units
shall be rented and occupied by, or if vacant, available for rental occupancy by those
whose annual household income at the time of initial occupancy is not greater than eighty
percent (80%) of the most recent annual median income, calculated and published by HUD
for the Fresno Metropolitan Statistical Area, applicable to such household's size, and at an
affordable rent consistent with HOME Program regulations (as provided at 24 C.F.R.
92.252) for the term of the Agreement. The DEVELOPER shall comply with the income
targeting requirements of 24 C.F.R 92.216.
25
8.3 Leasino the HOME Units. Before leasing any Affordable Units, the
DEVELOPER shall submit its proposed form of lease agreement for the CITY's review and
approval. The DEVELOPER covenants and agrees to utilize only leases that have been
approved in advance by the CITY. The CITY shall respond to the DEVELOPER's
submission of a sample lease agreement within thirty (30) days. Should the CITY not
respond within thirty (30) days of the lease agreement submittal, the DEVELOPER shall be
authorized to use the submitted sample lease agreement. Additionally, the DEVELOPER
agrees not to terminate the tenancy or to refuse to renew or lease with a tenant of the Units
assisted with HOME Funds except for serious or repeated violation of the terms and
conditions of the lease agreement, for violation of applicable federal, state, or local law, or
for other good cause. Any such termination or refusal to renew must be preceded by not
less than thirty (30) days' written notice served by the DEVELOPER or its authorized
management entity upon the tenant specifying the grounds for such action. The
DEVELOPER agrees it shall annually report to the CITY the number of leases that were
not renewed or terminated and the reason for such non-renewal or termination.
8.4 Lease of HOME Units Provisions. ln addition to the requirements of 24
C.F.R. 92.253, the leases are subject to the following:
A. The DEVELOPER shall include in its Leases for the HOME-
assisted Units, provisions which authorize the DEVELOPER to immediately terminate the
tenancy of any Household of which one or more of its members misrepresented any fact
material to the Household's qualification as a Very Low- or Low-lncome Household. Each
such lease agreement shall also provide that the Household is subject to annual
certification, and that, if the Household's annual income increases above the applicable
limits for Low-lncome, such Household's rent may be subject to increase to the lesser of: 1)
the amount payable by tenant under state or local law; or 2) thirty percent (30%) of the
Household's actual adjusted monthly income, except that, consonant with the Act, tenants
of HOME Funds-assisted units that have been allocated low income housing tax credits by
a housing credit agency pursuant to section 42 of the internal Revenue Code of 1g86 (26
U.S.C. 42) must pay rent governed by section 42.
8.5 FÍnal Manaqement Plan. Before leasing any Project Unit and at least sixty
(60) calendar days prior to the rehabilitation CompletÍon Date, the DEVELOPER shall
submit to CITY for review and approval a plan for marketing and managing the Unit
(hereinafter referred to as the "Final Management Plan"). The Final Management Plan
shall address in detail how the DEVELOPER plans to market the availability of Units to
prospective Low-lncome tenants and how the DEVELOPER plans to certify the eligibility of
potential household. The Final Management Plan shall also address how the
DEVELOPER and/or management entity plans to manage and maintain the Affordable
Units in accordance with HOME Program regulations at 92.251 Property Standards, and
shall include appropriate financial information and documentation. The Final Management
Plan shall contain detailed descriptions of policies and procedures with respect to tenant
selections and evictions. Topics to be covered in these procedures shatl include at a
minimum the following:
o lnterviewing procedures for prospective tenants;o Previous rental history of tenant with references;. Credit reports and checks;
26
o Criminal background checks;. Deposit amounts, purpose, use and refund policy;. EmploymenVlncome verification;o Occupancyrestrictions;. Income Limit;. Equal Housing Opportunity Statement;o Restrictions on use of the premises; and. TenanUlandlord dispute resolution procedures.
The Final Management Plan shall contain copies of all standardized forms
associated with the above listed topics. The Final Management Plan shall include a form
lease agreement that the DEVELOPER proposes to enter into with the Low-lncome
tenants. The DEVELOPER shall abide by the terms of this Final Management Plan,
approved by the CITY, in marketing, managing and maintaining the Affordable Units.
8.4 Property Manaoement. The DEVELOPER shall comply with the following:
A. Management Responsibilities. The DEVELOPER directly and/or
through its designated management entity, is specifically responsible for all management
functions with respect to the Project including, without limitation, the selection of tenants,
certification and re-certification of Household size and income, evictions, collections of
Rents and deposits, construction management, affirmative marketing, maintenance,
landscaping, routine and extraordinary repairs, replacement of capital items and security.
The CITY shall have no responsibility for such management of the Project.
8.5 Maintenance and Securitv. The DEVELOPER shall at its own expense
maintain the Project Unit in good condition, in good repair and in decent, safe, sanitary,
habitable and tenantable living conditions for the benefit of Unit occupants. The
DEVELOPER shall not commit or permit any waste on or to the Project, and shall prevent
and/or rectify any physical deterioration of the Project. The DEVELOPER shall maintain
the housing Units in conformance with all applicable federal, state and local laws
ordinances, codes and regulations, the Final Marketing Plan, and this Agreement.
8.6 Nondiscrimination. Nine (9) of the HOME-assisted Units shall be available for
occupancy on a continuous basis to households who are income eligible. The
DEVELOPER shall not illegally díscriminate or segregate in the rehabilitated complex, the
use, enjoyment, occupancy, conveyance of any part of the Project or Property on the basis
of race, color, ancestry, national origin, religion, sex, age, marital status, family status,
source of income/rental assistance subsidy, physical or mental disability, Acquired lmmune
Deficiency Syndrome (AIDS) or AlDS-related conditions (ARC), sexual orientation, or any
other arbitrary basis. The DEVELOPER shall othenryise comply with all applicable local,
State and federal laws concerning nondiscrimination in housing. Neither the DEVELOPER
nor any person claiming under or through the DEVELOPER, shall establish or permit any
such practice or practices of illegal discrimination or segregation with reference to the
selection, Iocation, number, use or occupancy of any Unit. All deeds or contracts made or
entered into by the DEVELOPER as to the Units or Project, or portion thereof, shatl contain
covenants concerning nondiscrimination consistent with this section. The DEVELOPER
shall include a statement in all advertisements, notices and signs for avaitability of Units for
rent to the effect that the DEVELOPER is an Equal Housing Opportunity Provider.
27
A. Nothing in this section is intended to require the DEVELOpER tochange the character, design, use or operation of the Project; or to require the
DEVELOPER to obtain licenses or permits other than those requiréd for the projeci.
8.7 Rent Schedule and Utilitv Allowance. The DEVELOPER covenants andagrees not to charge rent to tenants for HOME Units in an amount which exceeds those
rents prescribed to the Project as they associate with particular income and rent limitations
levels as establisle-! annually by HUD, consistent with the HOME Program requirements
applicable to the Affordable Units in the Fresno, California area, as eslablisneO Oy HUD,
and further covenants not to impose a monthly allowance for utility services to tenants ofsuch Affordable Units in excess of an amot nt approved by HUD in accordance with 24CFR92'252. The DEVELOPER agrees to furnish to the CITY with a certificate setting forththe maximum monthly rentals for the HOME Units and the monthly allowances for utilities
and services to Og_g[a¡qe_d during any annual period until the expiiation of the AffordabilityPeriod. The DEVELOPER shall reexamine the income of each ienant Household living iñthe Affordable Units at least annually.
ARTICLE 9. INSURANCE AND INDEMNITY AND BONDS
Without waiver of limitation, the parties agree as follows regarding DEVELOpER
lnsurance, lndemnity, and Bond Obligations:
Throughout the life of this Agreement,
in full force and effect all policies of insurance
s) either (i) admitted by the California lnsurance
e of California and rated not less than "A-Vll" inBest's lnsurance Rating Guide, or (ii) authorized by the CITY's Risk Manager. The
following policies of insurance are required:
(¡) COMMERCIAL GENERAL LIABILITY insurance which shall be at least asbroad as the most current version of lnsurance Services Office (lSO)
commercial General Liability coverage Form cG oo o1 and include
insurance for "bodily iljurv,' "property damage" and "personat and advertising
injury" with coverage for premises and operations (including the use of ownedand non-owned equipment), products and completed operations, and
contractual liability (including, without limitation, indemnig obligations under
the Agreement) with limits of liability of not ress than the foilowing:
$1,000,000 per occurrence for bodily injury and property damage
$1,000,000 per occurrence for personal and advertising injury
$2,000,000 aggregate for products and completeO operafiôné
$2,000,000 general aggregate applying separately to work performed
under the Agreement
(¡i) COMMERCIAL GENERAL LlABlLlry insurance which shatt be at as
board as the most current version of lnsurance Service Office (lSO) Business
Auto coverage Form cA 00 01, and include coverage for all owned, hired,
and non-owned automobiles or other licensed vehicles (Code 1-Any Autoj
with limits of liability of not less than $1,000,000 per accident for bodily injury
28
and property damage.
(¡¡¡) WORKERS' COMPENSATION insurance as required under the California
Labor Code.
(iv) EMPLOYEE LIABILITY insurance with limits of liability of not less than
$1,000,000 each accident, $1,000,000 disease policy limit and $1,000,000
diseased each employee.
(v) BUILDERS RISK (Course of Construction) insurance, obtained by the
Developer or subcontractor in an amount equal to the completÍon value of the
Project with no coinsurance penalty provisions. (Only required if the project
includes new construction of a building; or renovation of, or addition to, an
existing building.)
(vi) CONTRACTOR POLLUTION LIABILTY (Unless waived in writing by the
City's Risk Manager or his/her designee, Pollution Liability is required, by the
Developer or the Contractor for all environmental and water remediation
work and for all work transporting fuel. Unless waived ín writing by the City's
Risk Manager or his/her designee, the Pollution Liability is also required for
demolition, renovation, HVAC, plumbing or electrical (including, without
limitation, lighting) work on any structure built prior to the year 1990) i
insurance with limits of liability of not less than the following:
$1,000,000 per occurrence or claim
$2,000,000 general aggregate per annual policy period
ln the event the DEVELOPER purchases an Umbrella or Excess insurance policy(ies) to
meet the minimum limits of insurance set forth above, this insurance policy(ies) shall "follow
form" and afford no less coverage than the primary insurance policy(ies).
ln the event the DEVELOPER involves any lead-based, mold or asbestos environmental
haza¡d, either the Automobile Liability insurance policy or the Pollution Liability insurance
policy shall be endorsed to include Transportation Pollution Liability insurance covering
materials to be transported by the DEVELOPER pursuant to the HOME Agreement.
ln the event the DEVELOPER involves any lead-based environmental hazard (e.9., lead-
based paint), the DEVELOPER's Pollution Liability insurance policy shall be endorsed to
include coverage for lead based environmental hazards. ln the event the DEVELOPER
involves any asbestos environmental hazard (e.9., asbestos remediation), the
DEVELOPER's Pollution Liability insurance policy shall be endorsed to include coverage
for asbestos environmental hazards. ln the event the HOME Agreement involves any mold
environmental hazard (e.9., mold remediation), the Pollution Liability insurance policy shall
be endorsed to include coverage for mold environmental hazards and "microbial matter
including mold" within the definition of "Pollution" under the policy.
The DEVELOPER shall be responsible for payment of any deductibles contained in any
insurance policies required hereunder and the DEVELOPER shall also be responsible for
payment of any self-insured retentions. Any deductibles or self-insured retentions must be
29
declared to, and approved by, the CITY's Risk Manager or his/her designee. At the option
of the CITY's Risk Manager or his/her designee, either (i) the insurer shall reduce or
eliminate such deductibles or self-insured retentions as respects CITY, its officers, officials,
employees, agents and volunteers; or (ii) the DEVELOPER shall provide a financial
guarantee, satisfactory to CITY's Risk Manager or his/her designee, guaranteeing payment
of losses and related investigations, claim administration and defense expenses. At no
time shall CITY be responsible for the payment of any deductibles or self-insured
retentions.
All policies of insurance required hereunder shall be endorsed to provide that the coverage
shall not be cancelled, non-renewed, reduced in coverage or in limits except after thirty (3-0)
calendar day written notice has been given to CITY. Upon issuance by the insurer, bioker,
or agent of a notice of cancellation, non-renewal, or reduction in coverage or in limits, the
DEVELOPER shall furnish CITY with a new certificate and applicable èndorsements for
such policy(ies). ln the event any policy is due to expire during the work to be performed
for CITY, the DEVELOPER shall provide a new certificate, and applicable endorsements,
evidencing renewal of such policy not less than fifteen (15) calendar days prior to the
expiration date of the expiring policy.
The General Liability and Automobile Liability insurance policies shall be written on an
occurrence form. The Pollution Liability insurance policy shall be written on either an
occurrence form, or a claims-made form. The General Liability, Automobile Liability and
Pollution Liability insurance policies shall name CITY, its officers, officials, agents,
employees and volunteers as an additional insured. All such policies of insurance shãll be
endorsed so the DEVELOPER's insurance shall be primary and no contribution shall be
required of CITY. The coverage shall contain no special limitations on the scope of
protection afforded to CITY, its offTcers, officials, employees, agents and volunteers. lf the
DEVELOPER maintains higher limits of liability than the minimums shown above, the ClTy
requires and shall be entitled to coverage for the higher limits of liability maintained by the
DEVELOPER. The General Liability insurance policy shall also name tñe ClTy, its offiters,
offícials, agents, employees and volunteers as additional insureds for all ongoing and
completed operations. The Builders Risk (Course of Construction) insurance pólicy snall
be endorsed to name the CITY as loss payee. Any Workers' Compensation insúrance
policy shall contain a waiver of subrogation as to City, its officers, officials, agents,
employees and volunteers.
The DEVELOPER shall furnish CITY with all certificate(s) and applicable endorsements
effecting coverage required hereunder. All certificates and applicable endorsements are to
be received and approved by the CITY's Risk Manager or his/her designee before work
commences. Upon request of CITY, the DEVELOPER shall immediately furnish ClTy with
a complete copy of any insurance policy required under this HOME Agreement, including
all endorsements, with said copy certified by the underwriter to be a true and correct cop!
of the original policy. This requirement shall survive expiration or termination of tn¡i
Agreement.
Claims-Made Policies - lf any coverage required is written on a claims-made coverage
form:
(i) The retroactive date must be shown, and must be before the effective date of
the commencement of work by the DEVELOPER.
30
(ii) lnsurance must be maintained and evidence of insurance must be provided
for at least 5 years after completion of the work or termination of the HOME
Agreement, whichever first occurs.
(iii) lf coverage is canceled or non-renewed, and not replaced with another
claims-made policy form with a retroactive date prior to the effective date of the
HOME Agreement, or work commencement date, the DEVELOPER must
purchase extended reporting period coverage for a minimum of 5 years after
completion of the work or termination of the HOME Agreement, whichever first
occurs.
(iv) A copy of the claims reporting requirements must be submitted to ClTy for
review.
(v) These requirements shall survive expiration or termination of the HOME
Agreement.
lf at any time during the life of the HOME Agreement or any extension, the DEVELOPER,
its contractor, or any of its subcontractors fail to maintain any required insurance in full
force and effect, all work under this HOME Agreement shall be discontinued immediately,
and all payments due or that become due to the DEVELOPER shall be withheld until notice
is received by CITY that the required insurance has been restored to full force and effect
and that the premiums therefore have been paid for a period satisfactory to CITy. Any
failure to maintain the required insurance shall be sufficient cause for CITY to terminate the
HOME Agreement. No action taken by CITY hereunder shall in any way relieve the
DEVELOPER of its responsibilities under the HOME Agreement. tñe pñrase "fail to
maintain any required insurance" shall include, without limitation, notification received by
CITY that an insurer has commenced proceedings, or has had proceedings commenced
against it, indicating that the insurer is insolvent.
The fact that insurance is obtained by the DEVELOPER shall not be deemed to release or
diminish the liability of the DEVELOPER, including, without limitation, liability under the
indemnity provisions of the HOME Agreement. The duty to indemnify the ClTy shall apply
to all claims and liability regardless of whether any insurance policies are applicable. Ïne
policy limits do not act as a limitation upon the amount of indemnification to be provided by
the DEVELOPER. Approval or purchase of any insurance contracts or policies shall in no
way relieve from liability nor limit the liability of the DEVELOPER, its principals, officers,
agents, employees, persons under the supervision of the DEVELOPER, vendors,
suppliers, invitees, consultants, sub-consultants, subcontractors, or anyone employed
directly or indirectly by any of them.
ln the event of a partial or total destruction by the perils insured against of any or all of the
work and/or materials herein provided for at any time prior to the final completion of the
HOME Agreement and the final acceptance by the CITY of the work or materials to beperformed or supplied thereunder, the DEVELOPER shall promptly reconstruct, repair,
replace, or restore all work or materials so destroyed or injured at his/her sole cost and
expense. Nothing herein provided for shall in any way excuse the DEVELOPER or his/her
insurance company from the obligation of furnishing all the required materials and
completing the work in full compliance with the terms of the HOME Agreement.
lf the DEVELOPER should subcontract all or any portion of the services to be performed
under the HOME Agreement, the DEVELOPER shall require each subcontractor to provide
31
insurance protection in favor of CITY, its officers, officials, employees, agents and
volunteers in accordance with the terms of each of the preceding paragraplrs, except that
the subcontractors' certificates and endorsements shall be on file with the DEVEL'OPER
and the CITY prior to the commencement of any work by the subcontractor.
A. The above described policies of insurance shall be endorsed toprovide an unrestricted thirty (30) day written notice in favor of the ClTy, of policy
cancellation, change or reduction of coverage. ln the event any policy is due to expire
during the term of this Agreement, a new certificate evidencing renewal of such policy shallbe provided not less than fifteen (15) days prior to the expiration date of the eipiringpolicy(ies). Upon issuance by the insurer, broker, or agent of a notice of cancellation,
change or reduction in coverage, DEVELOPER or its contractors, as the case may be,
shall file with the Clry a certified copy of the new or renewal policy and certificates foriuch
policy.
B. DEVELOPER shall furnish the CITY with the certíficate(s) and
applicable endorsements for ALL required insurance prior to the ClTy's execution of this
Agreement. DEVELOPER shall furnish the CITY with copies of the actual policies upon the
request of the CITY at any time during the life of the Agreement or any extension.
At all times hereunder DEVELOPER shalr maintain the required
insurance in fullforce and effect.
9.2 lndemnitv. DEVELOPER shall indemnify, hold harmless and defend the
CITY and each of its officers, officials, employees, agents and votunteers from any and all
loss, liability, fines, penalties, forfeitures, costs and damages (whether in contraci, tort or
strict liability, including but not limited to_ personal injury, death at any time and property
damage) incurred by the CITY, DEVELOPER or any other person, añd from any anO ailclaims, demands and actions in law or equity (including attorney's fees and litigation
expenses), arising or alleged to have arisen directly or indirectly out of performance óf thisAgreement, DEVELOPER's obligations under the preceding sentence shall applyregardless of whether the CITY or any of its officers, officials, employees, agentð'or
vol-unteers are passively negligent, but shall not apply to any loss, liabiiity,-fines, pénafties,
forfeitures, costs or damages caused by the active negtigence or by the willful misconduct
of the clTY or any of its officers, officials, employees, agents or volunteers.
A. This section shall survive terminatíon or expiration of this Agreement.
9.3 Propertv lnsurance. Upon acquisition of the property, the DEVELOpER shallpay for and maintain in full force and effect, throughout the remaining life of this
Agreement, a policy(ies) of property insurance acceptable to the ClTy, coveriñg the project
premises, with limits reflective of the value rf the Project premises upon issùance of ihe
Certificate of Completion, or substantial completion of the Project referenced in this
Agreement, including fire and Extended Comprehensive Exposure (ECE) coverage in an
amount, form, substance, and quality as acceptable to the CITY's Risk Managér. The
CITY shall be added by endorsement as a loss payee thereon.
9.4 Bond Obliqations. The DEVELOPER or its General Contractor shall obtain,pay for and deliver good and sufficient payment and performance bonds along with a
32
Primary Obligee, Co-Obligee or Multiple Obligee Rider in a form acceptable to the CITY'
from a corporate surety, admitted by the California lnsurance Commissioner to do business
in the State of California and Treasury-listed, in a form satisfactory to the C¡TY and naming
the CITY as Obligee.
A. The "Faithful Performance Bond" shall be at least equal to 100% of the
DEVELOPER's estimated construction costs as reflected in the DEVELOPER's pro forma
budget, attached hereto as EXHIBIT "Cu, to the guarantee faithful performance of the
Project, within the time prescribed, in a manner satisfactory to the CITY, consistent with
this Agreement, and that all material and workmanship will be free from original or
developed defects.B. The "Payment Bond" shall be at least equal to 100% of construction
costs approved by the CITY to satisfy claims of material supplies and of mechanics and
laborers employed for this Project. The bond shall be maintained by DEVELOPER in full
force and effect untilthe Project is completed and until all claims for materials and labor are
paid and as required by the applicable provisions of Chapter 7, Title 15, Part 4, Division 3
of the California Civil Code.
C. The "Material and Labor Bond" shall be at least equal to 100% of the
DEVELOPER's estimated construction costs as reflected in the DEVELOPER's pro forma
budget, attached hereto as EXHIBIT 'C', to satisfy claims of material supplies and of
mechanics and laborers employed for this Project. The bond shall be maintained by the
DEVELOPER in full force and effect until the Project is completed, and until all claims for
materials and labor are paid, released, or time barred, and shall otherwise comply with any
applicable provision of the California Code.
D. ln lieu of the bonds required above, the CITY, in its sole discretion,
may accept from the DEVELOPER an lrrevocable Standby Letter of Credit issued with the
Clry named as the sole beneficíary in the amounts(s) of the bonds required above. The
Standby Letter of Credit is to be issued by a bank, and in the form, acceptable to the CITY.
This lrrevocable Standby Letter of Credit shall be maintained by the DEVELOPER in full
force and effect until the CITY is provided with a recorded Notice of Completion for the
construction of the Project and shall be subject to and governed by the laws of the State of
California.
ARTICLE IO. DEFAULT AND REMEDIES
10.1 Events of Default. Each of the following shall constitute an "Event of Default"
for purposes of this Agreement after the cure period in Section 10.2 has expired without a
cure:
A. The DEVELOPER's use of HOME Funds for costs other than Eligible
Costs or for uses not permitted by the terms of this Agreement;
B. The DEVELOPER's Failure to obtain and maintain the insurance
coverage required under this Agreement;
C. Except as othenruise provided in this Agreement, the failure of the
DEVELOPER to punctually and properly perform any other covenant or agreement
33
conta¡ned in this Agreement including without limitation the following: (1) the
DEVELOPER's substantial deviation in the Project scope of work specified in the Project
Description as identified in this Agreement, without the CITY's prior written consent; (2) the
DEVELOPER's use of defective or unauthorized materials or defective workmanship in
pursuit of the Project; (3) the DEVELOPER's failure to commence or complete the Project,
as specified in this Agreement, unless delay is permitted under Section 7.18 of this
Agreement; (a) cessation of work on the Project for a period of more than fifteen (15)
consecutive days (other than as provided at Section 7.18 of this Agreement) prior to
submitting to the CITY, pursuant to Section 7.19, certification that the Project is complete;
(5) any material adverse change in the condition of the DEVELOPER or the Project that
gives the CITY reasonable cause to believe that the Project cannot be completed by the
Completion Date according to the terms of this Agreement; (6) the DEVELOPER's failure to
remedy any deficiencies in record keeping or failure to provide records to the CITY upon
the CITY's request; (7) the DEVELOPER's failure to substantially comply with any federal,
state or local laws or applicable CITY restrictions governing the Project, including but not
limited to provisions of this Agreement pertaining to equal employment opportunity,
nondiscrimination and lead-based paint;
D. Any representation, warranty, or certificate given or furnished by or on
behalf of the DEVELOPER shall prove to be materially false as of the date of which the
representation, warranty, or certification was given, or that the DEVELOPER concealed or
failed to disclose a material fact to the CITY, provided, however, that if any representation,
warranty, or certification that proves to be materially false is due merely to the
DEVELOPER's inadvertence, the DEVELOPER shall have a thirty (30) day opportunity
after written notice thereof to cause such representation, warranty, or certification to be true
and complete in every respect;
E. The DEVELOPER shall file, or have filed against it, a petition of
bankruptcy, insolvency, or similar law, state or federal, or shall file any petition or answer
seeking, consenting to, or acquiescing in any reorganization, arrangement, composition,
readjustment, liquidation, dissolution, or similar relief, and such petition shall not have been
vacated within ninety (90) days; or shall be adjudicated bankrupt or insolvent, under any
present or future statute, law, regulation, under state or federal law, and such judgment or
decree is not vacated or set aside within ninety (90) days;
F. The DEVELOPER's failure, inability or admission in writing of its
inability to pay its debts as they become due or the DEVELOPER assignment for the
benefit of creditors;
G. A receiver, trustee, or liquidator shall be appointed for the
DEVELOPER or any substantial part of the DEVELOPER's assets or properties, and not
be removed within ten (10) days;
H. The failure of the DEVELOPER's to cause completion of the Project
prior to the completion date identified in EXHlBlT "B".
L The DEVELOPER's breach of any other material condition, covenant,
warranty, promise or representation contained in this Agreement not otherwise identified
within this Section'
J. Any substantial or continuous breach by the DEVELOPER of any
material obligation owned by the DEVELOPER imposed by any other agreement with
respect to the financing, of the Project, whether or not the CITY is a party to such
agreement after expiration of all notice and cure periods contained within such document.
10.2 Notice of Default and Opportunitv to Cure. The CITY shall give written notice
to the DEVELOPER of any Event of Default by specifying: (1) the nature of the event or
deficiency giving rise to the default; (2) the action required to cure the deficiency, if any
action to cure is possible, and (3) a date, which shall not be less than the lesser of any time
period provided in this Agreement, any time period provided for in the notice, or thirty (30)
calendar days from the date of the notice, by which such deficiency must be cured,
provided that if the specified deficiency or default cannot reasonably be cured within the
specified time, with the CITY's written consent, the DEVELOPER shall have an additional
reasonable period to cure so long as it commences cure within the specified time and
thereafter diligently pursues the cure in good faith. The CITY acknowledges and agrees
that the DEVELOPER shall have the right to cure any defaults hereunder and that notice
and cure rights hereunder shall extend to any and all partners of the DEVELOPER that are
previously identified in writing delivered to the CITY in the manner provided in this
Agreement.
10.3 Remedies Upon an Event of Default. Upon the happening of an Event of
Default and a failure to cure said Event of Default within the time specified, the CITY's
obligation to disburse HOME Funds shall terminate. The CITY may also at its option and
without notice institute any action, suit, or other proceeding in law, in equity or othen¡rrise,
which it shall deem necessary or proper for the protection of its interests and may without
limitation proceed with any or all of the following remedies in any order or combination that
the CITY may choose in its sole discretion:
A. Terminate this Agreement immediately upon written notice to the
DEVELOPER;
B. Bring an action in equitable relief: (1) seeking specific performance of
the terms and conditions of this Agreement, and/or (2) enjoining, abating or preventing any
violation of said terms and conditions, and/or (3) seeking declaratory relief; and
C. Pursue any other remedy allowed by law or in equity or under this
Agreement.
ARTICLE 11. GENERAL PROVIS¡ONS
Without waiver of limitation, the parties agree that the following general provisions shall
apply in the performance hereof:
11.1 Amendments. No modification or amendment of any provision of this
Agreement shall be effective unless made in wríting and signed by the parties hereto. The
CITY recognizes that other Project funders and equity investors may require revisions to
the Loan Documents to be consistent with their funding and investing requirements. The
CITY agrees to reasonably consider and negotiate as to any reasonable amendments to
35
this Agreement to address such requirements, subject to any necessary City Council
approval and approval as to form by the City Attorney.
11.2 Attornev's Fees. lf either party is required to commence any proceeding or
legal action to enforce or interpret any term, covenant or condition of this Agreement, the
prevailing party will be entitled to recover from the other party its reasonable attorney's fees
and legal expenses.
1 1.3 Bindinq on All Successors and Assiqns. Unless otherwise expressly provided
in this Agreement, all the terms and provisions of this Agreement shall be binding on and
inure to the benefit of the parties hereto, and their respective heirs, successors, assigns,
and legal representatives.
11.4 Counterparts. This Agreement may be executed in counterparts, each of
which when executed and delivered will be deemed an original, and all of which together
will constitute one instrument. The execution of this Agreement by any party hereto will not
become effective until counterparts hereof have been executed by all parties hereto.
11.5 Disclaimer of Relationship. Nothing contained in this Agreement, nor any act
of the CITY or of the DEVELOPER, or of any other person, shall in and by itself be deemed
or construed by any person to create any relationship of third party beneficiary, or of
principal and agent, of limited or general partnership, or of joint venture.
11.6 Discretionarv Governmental Actions. Certain planning, land use, zoning and
other permits and public actions required in connection with the Project including, without
limitation, the approval of this Agreement, the environmental review and analysis under
NEPA, CEAQ or any other statute, and other transactions contemplated by this Agreement
are discretionary government actions. Nothing in this Agreement obligates the CITY or any
other governmental entity to grant final approval of any matter described herein. Such
actions are legislative, quasi-judicial, or othen¡vise discretionary in nature. The CITY cannot
take action with respect to such matters before completing the environmental assessment
of the Project under NEPA, CEQA and any other applicable statutes. The CITY cannot and
does not commit in advance that it will give final approval to any matter. The CITY shall not
be liable, in contract, law or equity, to the DEVELOPER or any of its executors,
administrators, transferees, successors-in-interest or assigns for any failure of any
governmental entity to grant approval on any matter subject to discretionary approval.
11.7 Effective Date. This Agreement shall be effective upon the Parties' complete
execution following City Council approval.
11.8 Entire Aqreement. This Agreement represents the entire and integrated
agreement of the parties with respect to the subject matter hereof. This Agreement
supersedes all prior negotiations, representations or agreements, either written or oral.
11.9 Exhibits. Each exhibit and attachment referenced in this Agreement is, by the
reference, incorporated into and made a part of this Agreement.
11.10 Expenses lncurred Upon Event of Default. The DEVELOPER shall reimburse
the CITY for all reasonable expenses and costs of collection and enforcement, including
36
reasonable attorney's fees, incurred by the CITY as a result of one or more Events of
Default by the DEVELOPER under this Agreement.
11.11 Governinq Law and Venue. Except to the extent preempted by applicable
federal law, the laws of the State of California shall govern all aspects of this Agreement,
including execution, interpretation, performance, and enforcement. Venue for filing any
action to enforce or Ínterpret this Agreement will be Fresno, California.
11.12 Headinqs. The headings of the articles, sections, and paragraphs used in
this Agreement are for convenience only and shall not be read or construed to affect the
meaning or construction of any provision.
11.13 lnterpretation. This Agreement in its final form is the result of the combined
efforts of the parties. Any ambiguity will not be construed in favor or against any party, but
rather by construing the terms in accordance with their generally accepted meaning.
11.14 No Assiqnment or Succession. The DEVELOPER shall not sell, lease,
transfer, assign or otherwise dispose of all or a material part of any interest it might hold in
the Property without the prior written consent of the CITY, which consent shall not be
unreasonably withheld or delayed. Notwithstanding the foregoing, upon prior written notice
to the CITY, the DEVELOPER shall be permitted to assign its rights and obligation under
this Agreement with respond to the Project to the Partnership without the CITY's consent.
11.15 No Third-Party Beneficiarv. No contractor, subcontractor, mechanic,
materialman, laborer, vendor, or other person hired or retained by the DEVELOPER shall
be, nor shall any of them be deemed to be, third-party beneficiaries of this Agreement, but
each such person shall be deemed to have agreed: (a) that they shall look to the
DEVELOPER as their sole source of recovery if not paid, and (b) except as othen¡vise
agreed to by the CITY and any such person in writing, they may not enter any claim or
bring any such action against the CITY under any circumstances. Except as provided by
law, or as othenryise agreed to in writing between the CITY and such person, each such
person shall be deemed to have waived in writing all right to seek redress from the CITY
under any circumstances whatsoever.
11.16 No Waiver. Neither failure nor delay on the part of the CITY in exercising any
right under this Agreement shall operate as a waiver of such right, nor shall any single or
partÍal exercise of any such ríght preclude any further exercise thereof or the exercise of
any other right. No waiver of any provision of this Agreement or consent to any departure
by the DEVELOPER therefrom shall be effective unless the same shall be in writing, signed
on behalf of the CITY by a duly authorized officer thereof, and the same shall be effective
only in the specific instance for which it is given. No notice to or demand on the
DEVELOPER in any case shall entitle the DEVELOPER to any other or further notices or
demands in similar or other circumstances, or constitute a waiver of any of the CITY's right
to take other or further action in any circumstances without notice or demand.
11.17 Nonreliance. The DEVELOPER hereby acknowledges having obtained such
independent legal or other advice as it has deemed necessary and declares that in no
manner has it relied on the CITY, it agents, employees or attorneys in entering into this
Agreement.
37
11.18 Notice. Any notice to be given to either party under the terms of this
Agreement shall be given by certified United States mail, postage prepaid, return receipt
requested, at the addresses specified below, or at such other addresses as may be
specified in writing by the parties.
lf to the CITY: City of Fresno
Development and Resource Management Department
Housing and Community Development Division
Attn.: Division Manager
2600 Fresno Street, Room 3070
Fresno, CA 93721-3605
lf to DEVELOPER: Housing Authority of the City of Fresno
Attn.: Executive Director
1331 Fulton Mall
Fresno, C493721
11.19 Precedence of Documents. ln the event of any conflict between the body of
this Agreement and any exhibit or attachment hereto, the terms and conditions of the body
of this Agreement will control.
11.20 Recordino of Documents. The DEVELOPER agrees to cooperate with the
CITY and execute any documents required, promptly upon the CITY's request, the Deed of
Trust, and any other documents/instruments that the CITY requires to be recorded, in the
Official Records of Fresno County, California, consistent with this Agreement.
11.21 Remedies Cumulative. All powers and remedies given by this Agreement
shall be cumulative and in addition to those otherwise provided by law.
11.22 Severabilitv. The invalidity, illegality, or un-enforceability of any one or more
of the provisions of this Agreement shall not affect the validity, legality, or enforceability of
the remaining provisions hereof or thereof.
ilt
ilt
ilt
38
lN WITNESS WHEREOF, the parties have
California, the day and year first above written.
CITY OF FRESNO, a Municipal Corporation
By:
Naníe:
Title: Chief Administrative Officer
of the Housinq Authoritv of the Citv of Fresno.
California. the Sole Member and Manaqer of
Southeast Fresno RAD AGP, LLC. as
admin istrative qeneral partner
(Attach notary certificate of acknowledgment)
Attachments:
executed this Agreement in Fresno,
Date:
APPROVED AS TO FORM:
DOUG T. SLOAN
City Attorney
Date:q/a¡/te Date:
Southeast Fresno RAD, LP,,a California limited partnership
\-tt-tu
Date:
EXHIBIT A:
EXHIBIT B:
EXHIBIT C:
EXHIBIT D:
EXHIBIT E:
EXHIBIT F:
PROPERTY DESCRIPTION
PROJECT DESCRIPTION AND SCHEDULE
PROJECT BUDGET
s5-YEAR CASH FLOW STATEMENT
EXEMPLAR CERTIFICATION OF COMPLETION
EXEMPLAR PROMISSORY NOTE
Bruce Rudd, City Manager
(Attach notary certificate of acknowledgment)
ATTEST:
WONNE SPENCE, CMC
City Clerk
Deputy City Attorney
CALIFORNIA AII.PURPOSE ACKNOWLEDGMENT
State of California
County of
on q-
fi-¿sna
before me,
personally appeared
Name(s) of Signe(s)
ESICA CASTAÍIEDA
Commi¡slon , 2008360
tlolsry Public - C¡ltlorni¡
Frulno Coünty
Gomm.
who proved to me on the basis of satisfactory
evidence to be the personþ| whose nameþ) is/are
subscribed to the within instrument and acknowledged
to me that he/s y executed the same in
his/h ir signatureþ) on the instrument theperso or the entity upon behalf of which theperso acted, executed the instrument,
I certify under PENALTY OF PERJURY under the
laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and officialseal.
Signature:
Place Notary Seal Above
OPTIONAL
Though the information below is not required by law, ¡t may prove valuable to persons relying on the documenl
and could prevent fraudulent removal and reattachment of thÌs form to another documenL
Description of Attached ment7lt ,¿¿^onl - (t,Title or Type of Document:
Document Date:
Signer(s) Other
Capacity(ies)
Signer's Name:
Than Named Above:
Claimed by Signer(s)
n Corporate Officer - Title(s):
n lndividual
n Partner-! Limited n General
n Aftorney in Fact
I Trustee
n Guardian or
! Other:
Signer ls
Officer - Title(s):
n lndividual
n Paftner-tr Limited n General
n Attorney in Fact
n Trustee
n Guardian or Conservator
n Other:
Signer ls Representing:
q -)3-,
RIGHT THUMBPRINT
OF SIGNER
@ 2009 Nalional Notary Assoc¡ation . NationalNotary org . 1-800-US NOTABY (1-800-876-6827) ltem #5907
,J6tl
CALIFORNIA ALT.PURPOSE ACKNOWLEDGMENT
State of California
County of fntsr't o
before me,On
Cornh¡hr rñ
flotüt PrËtc - Caþflbl¡¡nCrnf
who proved to me on the basis of satisfactory
evidence to be the person(s) whose nameþ) is/are
subscribed to the within instrument and acknowledged
perso or the entity upon behalf of which theperso acted, executed the instrument.
I certify under PENALTY OF PERJURY under the
laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and officialseal.
.(rrâC 8-.
Corporate Officer - Title(s):
n lndividual
n Partner-n Limited n General
n Attorney in Fact
n Trustee
E Guardian or Conseruator
! Other:
Signer ls Representing:
Place Notary Seal Above
Though the information below is not required by law, it may prove valuable to persons relying on the document
and could prevent fraudulent removal and reattachment of this form to another document.
Description of Attached Document nl'- klo.Title or Type of Document:
Document Date:
Signe(s)Other
Capacity(ies)
Signer's Name:
Than Named Above:
Claimed by Signer(s)
n Corporate Officer - Title(s):
n lndividual
n Partner-n Limited n General
n Attorney in Fact
n Trustee
n Guardian or
n Other:
Signer ls
OF SIGNER
@ 2009 National Notary Associalion. Nat¡onalNotary org. 1-800-US NOTAFY (1-800-876-6827)
{f
EXHIBIT "A" - LEGAL DESCRIPTION
The Property is located at 4216 E. Hamilton Avenue, Fresno, CA 93702.
Real property in the City of Fresno, County of Fresno, State of California, described as follows:
LOTS 7, 8, 9, 10, 16, 17 AND THE EAST HALF OF LOT 18 OF GORDONDALE, ACCORDING TO
THE MAP RECORDED IN BOOK 8 OF PLATS, PAGE 45 IN THE CITY OF FRESNO, COUNTY
OF FRESNO, STATE OF CALIFORNIA.
EXCEPTING THEREFROM THE WEST 1O FEET OF SAID LOT 7 CONVEYED TO THE COUNTY
OF FRESNO, BY GRANT DEED RECORDED JUNE 13, 1967 IN BOOK 5448, PAGE 173 OF
OFFICIAL RECORDS OF FRESNO COUNTY.
APN : 47 1 -21 1 -01T, 47 1 -212-01t and portio n ol 47 1 -220-0 1 T
The Property is located at 510 S. Peach Avenue, Fresno, CA93727 .
Real property in the City of Fresno, County of Fresno, State of California, described as follows:
PARCEL B OF PARCEL MAP NO. 77-54 ACCORDING TO THE MAP THEREOF RECORDED IN
BOOK 27 PAGE 85 OF PARCEL MAPS, RECORDS OF SAID COUNTY.
APN: 463-050-22
År
EXHIBIT "B'' - PROJECT DESCRIPTION AND SCHEDULE
I. PROJECT DESCRIPTION
The Project consists of the rehabilitation and related on-site improvements of the Cedar Court
Apartments located al 4216 E. Hamilton Avenue, Fresno, CA 93702 and the lnyo Terrace
Apartments located at 510 S. Peach Avenue, Fresno, CA93727.
The Apartment complexes consist of one hundred ninety-three (193) affordable housing units of
which two units are reserved for on-site property managers. Of the one hundred and ninetythree
(193) units, nine (9) units will be reserved as floating HOME-assisted units for an affordability period
of fifty-five (55) years.
The scope of rehabilitation work is attached for each apartment complex.
HOME-FUNDED UNlTS
50% or less 2
80% or less 7
ffi,M,{Êa#::it
HOME funds will be made available by the CITY for payment of HOME eligible costs not to exceed
the lesser of one Million Five Hundred Thousand dollars and 00/100 ($t,500,000.00), the
aggregate HOME Program per unit cap (24 C.F.R. 92.250) for the nine (9) HOME-assisted Units as
determined by the CITY, as needed, for HOME eligible project rehabilitation costs.
II. PROJECT SCHEDULE
A. Commencement of Rehabilitation: December 1,2013
B. Completion of Rehabilitation: August 13, 2015
C. Stabilize Occupancy: November 1, 2015
'ç')
SCOPE OF REHABILITATION WORK
(q
Cedar Courts and lnyo Terrace Apartments
-lncreasing residential square footage by a total oÍ 25,129 sq. ft.
-Adding second bathroom for 3 BR units with only 1 bathroom
-Adding extra closet, living room, and or bedroom space to enhance livability
-5o/o of units ADA compliant
-All new flooring
-All new roofing
-All new painting
-All new bathroom fixtures
-25o/o+ increase in energy efficiency through replacement of windows, insulation, cooling
systems, and lighting
-New water heaters at 124 units (remaining water heaters recently replaced)
-Expanding counters with additional kitchen storage
-All new washers and dryers
-All new dishwashers
-All new exterior and interior doors
-All new hardscape patios in back of units
-New exterior color palette for units
Community Building
-Doubling size of existing community building to 6,648sf
-Welcome lobby for guests and residents
-Enhanced multLpurpose rooms and kitchens
-New computer rooms
-New playrooms
-Offices for on-site staff
Landscape
-New landscape for combined site acreage of 20 acres
-Combination of turf and drought-resistant landscaping
-New, comprehensive irrigation system
-Landscaping creates variety of spaces on site, including spaces that units can
personalize, shared spaces between a cluster of units, and several common spaces
-New children's play equipment
-New outdoor charcoal barbeques and seating
EXHIBIT '¡C'' - PROJECT BUDGET
.{ 1.1
Acquisition Costs:
lmprovements
Land
Closing, Title & Recording Costs
Other: Appraisal
SUBTOTAL
Construction
Basic Construction Contract
Contractor lns.
Contractor's Overhead & Profit
General Conditions
Prevailing Wage
Contingency
SUBTOTAL
Development
Soft Gost Contingency
Architect/Engineer
Environmental Assessment
Legal
Developer Fee
Furnishing
SUBTOTAL
Other Development
TCAC fees
lnsurance
Relocation
Consulting
Permits, Fees & Hookups
Lender lnspections
Title Recording
Construction Loan Fees
Construction lnterest
Physical Needs Assessment
Taxes
Capitalized Rent Subsidy
Marketing/Leasing Expenses
Market Study
Operating Reserues
Replacement Reserves:
SUBTOTAL
Total Development Costs $33,535,009 $33,s35,009 $1,500,000 $3,600,000 96,977,000 $21,458,009
HOME
$6,075.000 $6,075,000
$1.802.000 $902.000 $900,000
$7,877.000 $6,977.000 $900,000
$ r 3,734,91 5 $1.500.000 $12,234,915
$75.000 $75.000
$1.483.053 $1.483.053
$247,175 $247,175
$125.000 $125.000
$1.373.492 $1.373.492
$17.038.635 $1.500.000 $15.538.635
$275.000 $275.000
$1,295,380 s1.295.380
$75,000 $75,000
$215.000 $215.000
$2,000,000 $2.000.000
$325,000 $325,000
$4,185,380 $4,185,380
$144.685 $144,685
$120,000 $120.000
$1.158.000 $324.006 $833.994
$100,000 $100,000
$400,000 $400,000
$5.000 $5.000
s65.000 $65,000
$4 1 0,1 90 $41 0,1 90
$1.325.700 $1.325.700
s43 269 $43,269
$100.000 $100.000
$125,000 $125.000
$7s,000 $75,000
$20,000 $20,000
$317,'150 $317.'t50
$25.000 $25,000
$4.433.994 $3,600,000 $833.994
EXHIBIT '3D,' - s5.YEAR CASH FLOW STATEMENT
(s
(f
5
F¡esno RAD: Cedat Courts & Inyo Terroce - 55 YEAR CASH FLOW ANALYSß
S 7,754,4L7 S 1',798,277 5 t'843,234
Schedule Rental lncome
Draw on Reserve
GROSS POTENTIAT INCOME - HOUSING rsS 17S 1,935,548
(77,s32) s (79,471) 5 (81,4s8)CIs/e4l s (8s,s811 s 187,7211 s (8s,s14) s ls2,162l (s4,466) s (96,827],(9e,248) s í07,72s]-
$
Vacancy Loss
EFFECTIVE GROSS INCOME
Operating Expenses
Replacement Reserye
IOTAT EXPENSES & RESERVES
NET OPERATING INCOME
Bank Loan (1st Lien)
CASH FLOW AVAII.ABLE FOR SOTT DEBT
Fresno HA Seller Financing (2nd Lien) S 7,877,00o
FresnoHA(2ndlien) S 3,600,000
HRFC (2nd Lien) S 600,000
cityofFresno(3rdLíen) S 1,500,000
258,900 s 25s,966
s
S 268,900
155,008 154,306
71300 70,522
11,883 Lr,754
29,70A 29,384
720 713 s
$ r,se¿,gqg S r,4r2,722 S 1,462,168 5
ss7,900ss7,900ss7,900s57,900ss7,900s57,900ss7'90oss7'900s57'900s
it,tør,rst srzoz,rsr sr,z47,s7¡ it,zsg,oos g1,332,09s s1,376,691 çt,422,a4s $r,470'622 s1'520'068 I
,693
150,083
68,592
u,ß2
28,580
0.00
38s s
2s4,290 s
r47,532
67,426
11,238
28,O94
0.00
1,513,344 s
57,900 5
r,s77,244 s
1,566,311 s
57,900 s
7,624,2t7 s
1,621,131 s
57,900 s
1,679,031 s
206,692
119,911
54,803
9,L34
22,834
0.00
!,611,87!
57,900
r,735,77t
52,254
8,710
2r,774
0,00
000
ss
s 262'570 5
1s2,336
69,622
11,504
29,009
0.00
r44,668
66,777
11,020
27,549
0,00
747,473
64,657
r0,776
26,940
0.00
s 217,74L
s
s 237
r37,93r
63,038
10,506
26,266
0,00
(-
s 231,005
r34,O23
6]-,252
10,209
0.00
729,730
59,290
9,882
24,704
0.00
125,033
57,L43
9,524
23,810
0.00
Frcsno RAD: Cedar Courts & lnyo Terroce
o
\¡
2s%,JBs,aso- ,Js?É86 S 2,7s7,026 s 2,24s,802 5 2,307'e4t 2,359,495 s ñ4æ s zl:n',r4s { 2,s40,e18 s 2,604,447 s 2,669,552
Schedule Rental lncome
Draw on Reserue
GROSS POTENTIAL INCOME- HOUSING s 2,08s,4s0 s 2,191,026 s s s 2,478,94s s 2,s40,918 s z,eoa,ør s
-s.o% S (104,273) s (105,87s) s (1oe,ss1) s (112,290) s (11s,097) $ F77,97s1 (120,s24) s 1723,e4t,(127,046) $ (130,222) s (133,478)
Vacancy Loss
ÉFFECTIVE GROSS INCOME
Operating Expenses
Replacement Reserve
TOTAL EXPENSES & RESERVES
NET OPERATING INCOME
Bank Loan (1st Lien)
CASH FLOW AVAIL.ABLE FOR SOFT DEBT
Fresno HASeller Financing (2nd Lien)
Fresno HA (2nd Lien)
HRFc (2nd Lien)
City of Fresno (3rd L¡en)
2,354,998 s 2,4
ñ zror,ßE T 2,zs;J66 5 2,366,803 sãF'' s,¡ss S 1,es2'784 S 2'062's32 S
S 57.900 S s7,900 S s7,900 S s7,900 S s7,900 S 57,900 S
S 1,794,495 S r,8ss,277 $ 1,918,186 I 1,s83,295 S 2,0s0,684 5 2,720'432 5
szr $
s7,soo s s7,soo s s7,9oo 5 s7,900 s
2,tsz,62o S 2,267,316 $ 2,344,656 $ 2'424,703 S
49,5L7
28,728
13,130
2,188
5,477
0.00
2,449,64r
57,900
2ÞO7,547
15,555
7,566
L,267
3,!52
0.00
S 136,165 104,938 s186,581 s
186,681
7,817,000 108,307
3,600,000 49,499
600,000 8,250
1,500,000 20,625
s s s
r07;179
46,516
7,753
19,382
0.00
94,736
43,297
7,276
18,040
0,00
87,151
39,830
6,638
16,596
0.00
78,999
36,10s
6,O7'Ì
15,044
0.00
70,252
32,r07
5,351
13,378
0.00
60,882
27,825
4,637
77,594
0.00
a7,662
50,859
23,244
3,874
9,68s
0.00
40,!52
18,350
3,058
7,646
0.00
153,289 150,215 s
0.00
\n
Fresno RAD: Cedør Courts & lnyo Tetruce will be refinanced in Year
2.5%s 2,736,297 s 2,804,699 s 2,874,816 2,946,686 s 3,020,354 sprs"86, s 3"173¿s' s 3,2s2,s90 5 3,333,90s s 3,417,2s3 3,502,684
s 17,ss3 s 42,78s 5 59,567 s 97,959 s 128,065schedule Rental lncome
Draw on Reserve
GROSS POTENfIAL INCOME. HOUSIN6 s s52,s 2,822,252 s 2,917,601 $s 3,118,323
(140,23s1 s (143,741) s (147,334) s (1s1,018) s (1s47s3) s (1s8,663) s (162,630) s (166,69s) s (170,863)(17s,134)
-s.0% s (135,81s) sVacancy Loss
EFFECTIVE GROSS INCOME
0perating Expenses
Replacement Reserue
TOTAL EXPENSES & RESERVES
NETOPERATING INCOME
Bank Loan (1st Lienl
CASH FLOWAVAILABLE FOR SOFT DÊBT
Fresno HA Seller Financing (2nd Lien)
Fresno HA (2nd Lien)
HRFC (2nd Lien)
city of Fresno (3rd Lien)
s
ã 3'22s'7os s 3'338'6os s 3'4ss'460 s
s 57,9005 s7,9OOs 57,900s s7,9o0s s7,900s s7,9oo5 s s7',90os s7',900s s7'900$
S z,ss3,zi¡ S 2,682,017 S z,7i3,B6r S z,BEB,919 S z,s;,sos i g,oos,rsa $ ¡,rz 3,283,609 S 3,396,s09 S 3,s13,360 $
s s 3,014,596
0 s (1s9,931)
3,576,401
57,900
3,634,301
6,198 $
5
sI
s
s
sI
s
$
000
000
000
000
000 000 000
3,596 o 0 0
7,644 0 0 0
274000
685000
o.oo 0.oo 0 00 0 00
o$
7,877,000
s 3,600,000
S 600,000
s 1,s00,000
À
\
Fresno RAD: Cedar Courts & lnyo Terroce
Schedule Rental lncome
Draw on Reserye
2.5%5 3,s90,251 S 3,680,008 S 3,772,008 S 3,866,308 3,962,956s 4,052,040s 4,163,s91s 4,267,68rs 4,374,373s 4,483,732s 4,s9s,82s
GROSSPOTENTTAilNCOME-HOUS|NGs3,s90,2s1s3,680,00853,772,008s3,866,308$3,962,965s4,062,040$4,153,591$4,267,68rs4,374,371s4,483,732s4,s9s,82s
vacancyLoss -s.0%s (17s,s13)s (184,000)s (188,600)s (193,31s)s (1s8,148)s (203,102)s (208,180)s (213,384)5 (218J19)s 1224,187)s (229,791].
EFFECTTVEGROSSTNCOME s 3,410,739 s 3,496,007 s 3,s83,407 5 3,672,993 s 3,764,817 s 3,858,938 $ 3,9ss,411 s 40s4,296 s 4,15s,6s4 $ 4,2s9,54s s 4,366,034
operatinsExpenses 3.s%S 3,701,s75 S 3,831,131 S 3,96s,220 S 4104,003 S 4,247,643 5 4,396,311 S 4,ss0,181 S 4,709,438 S 4,874,268 S s,0M,867 S s,22r,ßa
Replacement Reserue
TOTAL EXPENSES & RESERVES
$ sz,goos s7,so0s s¿e0os s7,900s 57,900s s7,e0os 57,soos s7,900s sz,goos s7,s00s sz,goo
s3,7s9,475s3,889,031s4,021,120s4,161,903$4,30s,s43$4,454,27rs4,608,081s4,767,338$4,932,158ss,r02,767ss,279,338
NET OPERATING INCOME s (s40,7261 s s (6s2,6701 s (713,041) s
Bank Loan (lst Lien)
CASH FLOW AVAITABLE FOR SOFT DEBT s (s40,726) s s f6s2,570) s (713,041) s (776,s14) s (913,304)
0
0
0
n
0
0
0
000
000
000
000
000
0
0
0
0
0.00
0000
0000
0000
0000
000 000 000 0.00
0
0
0
0
7,877,000
3,500,000
600,000
1,500,000
Fresno HAseller Financ¡ng (2nd Lien)
Fresno HA (2nd Lien)
HRFC (2nd Lien)
C¡ty of Fresno (3rd Lien)
0.00
^{\\o
Fresno RAD: Cedar Courts & lnyo Terrace
Schedule Rental lncome
Draw on Reserye
2.s%s 4,770,727 s 4,828,489 s 4,949,20L s s,072,931 5,199,754 s 5,329,748 5,462,992 5,s99,557 s s,739,5s6
GROSS POTENTIAT INCOME - HOUSING S s.199.7s4 3 s 5,599,567 s
Vacancy Loss -s.0% 5 (23s,s36) S 1247,424) S Q47,460], S 12s3,6471 s (2ss,s88) s (266,487) s (273,1s0) s 1279,e781 5 (285,978)
EFFECÍIVE GROSS INCOME f4L s
3.s%s 5,404188 s s,s93,335 s 5,789,101 s 5,991,720 s 6,201,430 s 6,418,480 s 5,643,!27 s 6,875,636 s 7,7L6,284
s s7,9OOs s7,900s s7,900s s7,9005 s7,eo0s s7,e00s s7,e00s s7,900s s¿900
ss,462,088ss,6s1,23sss,S47,001$6,04s,520s5,2ss,33095,476,3S0s6,701,O27s6,933,s36s7,174,784
s
operating Expenses
Replacement Reserue
TOTAT EXPENSES & RE5ERVES
NET OPERATING INCOME
Bank Loan (1st Lien)
CASH FLOW AVAILABTE FOR SOFT DEB'T
0000
0000
0000
0000
0.00 0.00 0 00 0 00
0
0
u
000
0
0
0
0
000
0
0
0
0
0,00
0
0
0
0
0.00
7,877,O00
3,600,000
600,000
1,500,000
Fresno HA Seller Financing (2nd Lienl
Fresno HA (2nd LIen)
HRFC (2nd tlen)
city of Fresno (3rd L¡en)
0.00
EXHIBIT '¡E''. CERTIFICATE OF COMPLETION
Recorded at the Request of
and When Recorded Return to:
City of Fresno
Development and Resource Management Dept.
Housing and Community Development Division
2600 Fresno Street, Room 3070
Fresno, CA 93721-3605
(SPACE ABOVE THIS LINE
This Certificate of Completion is recorded at the request and for the benefit of the City of Fresno
and is exempt from the payment of a recording fee pursuant to Government Code Section 6103.
A.P.N.: 471-211-01T, 471-212-01T, and port¡on o1471-220-01T, and 463-050-22
City of Fresno
Bruce Rudd, City Manager
Date:
g
Certificate of Completion
A.P.N.: 471-211-01T, 471-212-01T, and portion ot 471-220-01T, and 463-050-227
Recitals:
A. By a HOME lnvestment Partnerships Program Agreement dated 2013,
('HOME Agreement") between the City of Fresno, a municipal corporation ("C|TY"), Southeast
Fresno RAD, LP ("DEVELOPER"), the DEVELOPER agreed to rehabilitate the Cedar Court
Apartments and lnyo Terrace Apartment, grounds and related on-site improvements upon the
Property described in EXHIBIT "4" attached to the HOME Agreement, and made part hereof by this
reference (the "Propۖy"), with assistance of HOME Funds while meeting the affordable housing,
income targeting and other requirements of 24 C.F.R. 92 according to the terms and conditions of
the HOME Agreement and Loan Documents and other documents/instruments referenced therein.
B. The HOME Agreement or a memorandum of it was recorded on , âs
lnstrument No. in the Official Records of Fresno Gounty, California.
C. Under the terms of the HOME Agreement, after the DEVELOPER completes the
Project, the DEVELOPER may ask the CITY to record a Certificate of Completion.
D. The DEVELOPER has asked the GITY to furnish the DEVELOPER with a recordable
Certificate of Completion.
E. The CITY's issuance of this Certificate of Completion is conclusive evidence that the
DEVELOPER has completed the Project as set forth in the HOME Agreement.
NOW THEREFORE:
1. The CITY certifies that the DEVELOPER commenced rehabilitation of the Project on
full compliance with the HOME Agreement.
2. This Certificate of Completion is not evidence of the DEVELOPER's compliance with, or
satisfaction of, any obligation to any mortgage or security interest holder, or any mortgage or security
interest insurer, securing money lent to finance work on the Property or Project, or any part of the
Property or Project.
3. This Certificate of Completion is not a notice of completion as referred to in California
Civil Code Section 3093.
4. Nothing contained herein modifies any provision of the HOME Agreement.
ilt
ilt
ilt
1ç
lN WITNESS WHEREOF, CITY has executed this Certificate of Completion as of this
day of ,2
CITY OF FRESNO
By:Date:
Bruce Rudd, City Manager
(Attach notary certificate of acknowledgment)
ATTEST:
WONNE SPENCE, CMC
CITY CLERK
APPROVED AS TO FORM:
DOUG T. SLOAN
CITY ATTORNEY
By:By:
Deputy Tracy Parvanian, Deputy City Attorney
Date Date:
Southeast Fresno RAD, LP, a California limited partnership
By:Date:
Name: Preston Prince
Title: Executive Director
(Attach notary certifìcate of acknowledgment)
{(/
EXHIBIT "F" . PROMISSORY NOTE
DO NOT DESTROY THIS NOTE: When paid, this note, must be surrendered to Borrower for
Cancellation.
PROMISSORY NOTE
Secured by Deed of Trust
Loan Amount: $1.500.000
Fresno, California
Date:
Promise to Pav. For value received, the undersigned, Housing Authority of the City of Fresno, a body
corporate and politic ("Borrower"), promises to pay to the order of the City of Fresno, a California
municipal corporation ("Lender"), the sum of One Million Five Hundred Thousand dollars and 00/100
($1,500,000.00), to the extent that such funds are loaned to Borrower, with interest on the unpaid
principal balance running from the date of disbursement with simple interest at the rate of 4o/o
annually in accordance with the HOME lnvestment Partnerships Agreement dated 2013,
entered into between the Lender and BORROWER, ("Agreement"), with all principal and interest due
and payable on or before the earlier of (i) Borrower's uncured default under the Agreement with
respect to the Project, and (ii) fifty-five (55) years from the date of this Note, ("Maturity Date"), on
which date the unpaid balance of principal with unpaid interest thereon shall be due and payable,
along with attorney's fees and costs of collection, and without relief from valuation and appraisement
laws.
This is a Residual Receipts Note. Principal and interest payments equal to 10% of annual
Residual Receipts, to the extent that Residual Receipts exist and are itemized in audited financial
statements supplied to Lender with each payment hereunder, shall be due one hundred eighty (180)
days following the end of the year in which the Project converts to its permanent phase under the
Financing, and said päyment continues each successive year thereafter until the Maturity Date, upon
which all principal and interest shall be due and payable (prorated amounts to be paid for the first and
last year of the Note). Any failure to make a payment required hereunder within ten (10) days after
such payments are due shall constitute a default under the Agreement with respect to the Project and
this Note. lt shall not be a default hereunder if no payment was made because Project Residual
Receipts did not exist for any particular year. Additionally any failure to timely submit to Lender
audited financial statements within th¡rty (30) days after such financial statements are due shall
constitute a default under the Agreement with respect to the Project and Note.
Residual Receipts means in each operating year after the conversion of the Project financing to its
permanent phase, the sum of: (i) all cash received by the Project from (A) rents, lease payments,
and all sources generally considered in the apartment industry to be "other income" (which does not
include payments for optional services provided by Borrower), (B) payments from HUD under a
Housing Assistance Program Section I Contract to the Project, if any, and excluding (a) tenant
security or other deposits required by law to be segregated, and (b) interest on reserves not available
for distribution, and (ii) the net proceeds of any insurance (including rental interruption insurance),
other than fire and extended coverage and title insurance, to the extent not reinvested, less the sum
of: (i) the Project related annual fee payable to the investment limited partner and the annual fees
payable to the nonprofit managing general partner; (ii) all payments on account of any loans
(including unpaid principal and accrued reasonable interest) made for the benefit of the Project by the
Borrowers pursuant to the terms of any equity investor limited partnership agreement, and; (iii)
payments towards the deferred developer fee (including repayment of loans or capital contributions
made by a partner to a partnership specifically for the purpose of paying the deferred developer fee);
l:'l
(¡v) contributions to any prudent and reasonable cash reserves for working capital, capital
expenditures, repairs, replacements and anticipated expenditures, in such amounts as may be
reasonably required by the lenders to the Project for the operation of the Project not to exceed the
amount required by the Project's permanent lender, annually adjusted in proportion to the average
increase of the following indices (a) the United States Bureau of Labor Statistics for Hourly Wage
Rates of all workers in manufacturing, and (b) of all Commodity Wholesale Prices, said indices shall
be re-defined to the mutual satisfaction of the parties in the event of change in form and basis of
indices, all increases shall use the indices for calendar year 2010 as their base; (v) the payment of
principal and interest, and any associated fees, expenses, and costs, with respect to the Financing;
(vi) payments made to the investors which are required to reimburse the investors a portion of its
capital contribution in relation to the Project when there is a shortfall in funding initially promised
pursuant to any equity investor or partnership agreement; (vii) the payment of any deferred
development costs.
Operatino Expenses means actual, reasonable and customary (for comparable quality, newly
constructed rental housing developments in Fresno County) costs, fees and expenses directly
incurred, paid, and attributable to the operation, maintenance and management of the Affordable
Project in a calendar year, including, without límitation: painting, cleaning, repairs, alterations,
landscaping, utilities, refuse removal, certificates, permits and licenses, sewer charges, real and
personal property taxes, assessments, insurance, security, advertising and promotion, janitorial
services, cleaning and building supplies, purchase, repair, servicing and installation of appliances,
equipment, fixtures and furnishings which are not paid from the capital replacement reserve, fees and
expenses of property management and common area expenses, fees and expenses of accountants,
attorneys and other professionals, the cost of social services, repayment of any completion or
operating loans including any and all deferred contractor's fees per the Budget, made to Borrower, its
successors or assigns, and other actual operating costs and capital costs which are incurred and paid
by Borrower, but which are not paid from reserve accounts.
All capitalized terms used in this Note, unless otherwise defined, will have the respective meanings
specified in the Agreement. ln addition, as used in this Note, the following terms will have the
following meanings:
Business Dav means any day other than Saturday, Sunday, or public holiday or the
equivalent for banks generally under the laws of California. Whenever any payment to be
made under this Note is stated to be due on a day other than a Business Day, that payment
may be made on the next succeeding Business Day.
Note Maturitv Date means fifty-five (55) years from the date the permanent loan converts.
This Note, and any extensions or renewals hereof, is secured by a Deed of Trust and
Assignment of Rents, on real estate in Fresno County, California, that provides for acceleration upon
stated events, dated as of the same date as this Note, and executed in favor of and delivered to the
Lender ("Deed of Trust"), insured as a 3'd position lien on the Property.
Time is of the essence. lt will be a default under this Note if Borrower defaults under the
Agreement, any other Loan Document with the Lender, or this Note and such default continues
beyond the notice and cure period as provided in such documents. ln the event of a default by
Borrower with respect to any sum payable under this Note and the failure to cure such default within
ten (10) days, the Borrower shall pay a late charge equal to the lesser of two percent (2o/o) of any
outstanding payment or the maximum amount allowed by law. All payments collected shall be
"rl
appl¡ed first to payment of any costs, fees or other charges due under this Note or any other Loan
Documents then to the interest and then to principal balance. On the occurrence of an uncured
default or on the occurrence of any other event that under the terms of the Loan Documents give rise
to the right to accelerate the balance of the indebtedness, then, at the option of Lender, this Note or
any notes or other instruments that may be taken in renewal or extension of all or any part of the
indebtedness will immediately become due without any further presentment, demand, protest, or
notice of any kind. Lender acknowledges and agrees that it shall send notice of any default
hereunder to the limited partners of Borrower and shall accept any cure offered by such limited
partners on the same basis as it would accept a cure from Borrower,
The indebtedness evidenced by this Note may, at the option of the Borrower, be prepaid in
whole or in part without penalty. Lender will apply all the prepayments first to the payment of any
costs, fees, late charges, or other charges due under this Note or under any of the other Loan
Documents and then to the interest and then to the principal balance.
All Loan payments are payable in lawful money of the United States of America at any place
that Lender or the legal holders of this Note may, from time to time, in writing designate.
Borrower agrees to pay all costs including, without limitation, reasonable attorney fees,
incurred by the holder of this Note in the successful enforcement of payment, whether or not suit is
filed, and including, without limitation, all costs, reasonable attorney fees, and expenses Íncurred by
the holder of this Note in connection with any bankruptcy, reorganization, arrangement, or other
similar proceedings involving the Borrower that in any way affects the exercise by the holder of this
Note of its rights and remedies under this Note. All costs incurred by the holder of this Note in any
action undertaken to obtain relief from the stay of bankruptcy statutes are specifically included in
those costs and expenses to be paid by Borrower.
Any notice, demand, or request relating to any matter set forth herein shall be in writing and
shall be given as provided in the Agreement.
No delay or omission of Lender in exercising any right or power arising in connection with
any default will be construed as a waiver or as acquiescence, nor will any single or partial exercise
preclude any further exercise. Lender may waive any of the conditions in this Note and no waiver will
be deemed to be a waiver of Lender's rights under this Note, but rather will be deemed to have been
made in pursuance of this Note and not in modification. No waiver of any default will be construed to
be a waiver of or acquiescence in or consent to any preceding or subsequent default.
The Deed of Trust provides as follows:
Except as provided herein or in the Agreement, if the Trustor/Grantor shall sell, convey or
alienate said property, or any part thereof, or any interest therein, or shall be divested of his
title or any interest therein in any manner or way, whether voluntarily or involuntarily, without
the written consent of the Beneficiary being first had and obtained, Beneficiary shall have
the right, at its option, except as prohibited by law, to declare any indebtednese or
obligations secured hereby, irrespective of the maturity date specified in any Note
evidencing the same, immediately due and payable.
Lender may transfer this Note and deliver to the transferee all or any part of the Property
then held by it as security under this Note, and the transferee will then become vested with all the
powers and rights given to Lender; and Lender will then be forever relieved from any liability or
,'14
responsibility in the matter, but Lender will retain all rights and powers given by this Note with respect
to Property not transferred.
lf any one or more of the provisions in this Note is held to be invalid, illegal, or
unenforceable in any respect by a court of competent jurisdiction, the validity, legality, and
enforceability of the remaining provisions will not in any way be affected or impaired. This Note will
be binding on and inure to the benefit of Borrower, Lender, and their respective successors and
assigns.
Borrower and Lender agree that this Note will be deemed to have been made under and will
be governed by the laws of California in all respects, including matters of construction, validity, and
performance, and that none of its terms or provisions may be waived, altered, modified, or amended
except as Lender and Borrower may consent to in a writing duly signed by Borrower or Lender or its
authorized agents.
This Note shall be nonrecourse to Borrower and all its constituent members and may be
prepaid at any time without penalty. Neither Borrower nor any of its general and limited partners shall
have any personal liability for repayment of the Loan. The sole recourse of the Lender under the
Loan Documents for repayment of the Loan shall be the exercise of its rights against the Property
pursuant to the Deed of Trust and Lender shall have no right to seek or recover any deficiency
amount from Borrower or any partner of Borrower.
ill
ilt
ilt
lN WITNESS THEREOF, Borrower has caused this Promissory Note to be executed by its
authorized agent as of the date and year first above written.
BORROWER
Southeast Fresno RAD, LP, a California limited partnership
By:
Name: Preston Prince
Title: Executive Director
(Attach notary certificate of acknowledgment)
Date:
¡rD
EXHIBIT 'fG'' - EXEMPLAR DEED OF TRUST
Recorded at the Request of
and When Recorded Return to:
City of Fresno
Development and Resource Management Dept.
Housing and Community Development Division
2600 Fresno Street, Room 3070
Fresno, CA 93721-3605
THIS L|NE FOR RECORDER'S USE ONLY)
TITLE ORDER NO.
ESCROW NO.
APN NO. :471-211-0'1T,471-212-01, and portion oÍ 471-22ù011, and 463-050-227
DEED OF TRUST
Fresno RAD, LP, a California limited partnership (herein "Borrower"), Placer Title Company, a California
Corporation (herein "Trustee"), and the City of Fresno, a Municipal Corporation organized and existing under
the laws of the State of California whose address is 2600 Fresno Street, Fresno, California 93721 (herein
"Beneficiary" and "Lender").
Borrower, in consideration of the indebtedness herein recited and the trust herein created, does irrevocably
grant and convey to Trustee, in trust, with power of sale, all Borrower's right, title, and interest now owned or
hereafter acquired in the real property ('Land") known as 4216 E. Hamilton, Fresno, CA 93702 and 510 S.
Peach Avenue, Fresno, CA93727 in Fresno County, California and more particularly described in the Attached
Exhibit A, incorporated by reference (Borrower agrees that any greater to the Land later acquired during the
term of this Deed of Trust will be subject to this Deed of Trust), together with the rents, issues, and profits,
subject however, to the right, power, and authority granted and conferred on Borrower in this Deed of Trust to
collect and apply the rents, issues, and profits; and
Borrower also írrevocably grants, transfers, and assigns to Trustee, in trust, with power of sale, all of
Borrower's right, title and interest now owned or later acquired to the following property (including the rights or
interests pertaining to the property) located at the Property:
(1) All buildings ("Buildings") and improvements now or later on the land and all easements, rights,
appurtenances, water and water rights, minerals and mineral rights; all machinery, equipment,
appliances, and fixtures for the generation or distribution of air, water, heat, electricity, light, fuel,
or refrigeration or for ventilating or sanitary purposes or for the exclusion of vermin or insects or
for the removal of dust, refuse, or garbage; all wall safes, built-in furniture, and installations,
window shades and blinds, light fixtures, fire hoses and brackets, screens, linoleum, carpets,
furniture, furnishings, fixtures, plumbing, laundry tubs and trays, refrigerators, heating units,
stoves, water heaters, incinerators, and communication systems and installations for which any
Building is specially designed; all of these item, whether now or later installed, being declared to
be for all purposes of this Deed of Trust a part of the Land, the specific enumerations in this
Deed of Trust not excluding the general;
(2) The rents, issues, profits, and proceeds relating to the foregoing; and
(3) The Property to the extent not included on clauses (1) and (2) above.
¡(
TO SECURE, in order of priority that Beneficiary determines:
(1) Payment of the indebtedness evidenced by a note of Borrower of even date with this Deed of
Trust in the principal amount of One Million Five Hundred Thousand dollars and 00/100
($1,500,000.00) ("Note"), payable to Beneficiary or order, and all extensions, modifications, or
renewals of that note;
(2) Payment of the interest on that indebtedness according to the terms of the Note;
(3) Payment of all other sums (with interest as provided herein) becoming due and payable to
Beneficiary or Trustee pursuant to the terms of this Deed of Trust;
(4) Performance of every obligation contained in this Deed of Trust, the Note, the HOME
securing any indebtedness secured by this Deed of Trust, and any agreements, supplemental
agreements, or other instruments of security executed by Borrower as of the same date of this
Deed of Trust or at any time subsequent to the date of this Deed of Trust for the purpose of
further securing any indebtedness amending this Deed of Trust or any instrument secured by
this Deed of Trust (collectively the "Loan Documents"); and
(5) Payment of all other obligations owed by Borrower to Beneficiary that by their terms recite that
they are secured by this Deed of Trust, including those incurred as primary obligor or as
guarantor.
Borrower covenants that Borrower is lawfully seized of the estate hereby conveyed and has the right to grant
and convey the Property, and that the Property is unencumbered except for encumbrances of record.
Borrower covenants that Borrower will forever warrant and will defend the grant made in this Deed of
Trust against all claims and demands, subject to encumbrances of record. Borrower covenants that Borrower
will maintain and preserve the lien of this Deed of Trust until all the indebtedness under the Note is paid in full.
Borrower represents and warrants to Beneficiary that as of the date of this Deed of Trust Borrower is a validly
existing, and in good standing under the laws of the State of California and is qualified to do business in
California; that Borrower has the requisite power and authority to own, develop, and operate the property; and
that Borrower is in compliance with all laws, regulations, ordinances, and orders of public authorities applicable
to it.
Borrower represents and warrants to Beneficiary that as of the date of this Deed of Trust the execution,
delivery, and performance by the Borrower and the borrowings evidenced by the Note are within the power of
the Borrower; have been duly authorized by all requisite corporate or partnership actions, as appropriate; has
received all necessary governmental approvals, and will not violate any provision of law, any order of any court
or agency of government, the charter documents of Borrower, or any indenture, agreement, or any other
instrument to which Borrower is a party or by which Borrower or any of it property is bound, nor will they
conflict with, result in a breach of, or constitute (with due notice and lapse of time) a default under any
indenture, agreement, or other instrument, or result in the creation or imposition of any lien, charge, or
encumbrance of any nature on any of the property or assets of Borrower, except as contemplated by the
provisions of the Loan Documents; and each of the Loan Documents, when executed and delivered to
Beneficiary, will constitute a valid obligation, enforceable in accordance with its terms.
þ>.
Borrower represents and warrants to Beneficiary that as of the date of this Deed of Trust that the Property is
not used principally for agricultural or grazing purposes; that Borrower is engaged in the development and
operation of lmprovements to the Property; and that the principal purpose of the Loan is the acquisition,
development and/or the operation of the lmprovements to the Property.
UNIFORM COVENANTS. Borrower and Lender covenant and agree as follows:
1. Pavment of Principal. Borrower shall promptly pay when due the principal indebtedness evidenced by the
Note.
2. Hazard lnsurance. Bonower, at its sole cost and expense, for the mutual benefit of Borrower and
Beneficiary, shall keep the improvements now existing or hereafter erected on the Property insured against
loss by fire, hazards included within the term "extended coverage", and such other hazards as Lender may
require and in such amounts and for such periods as Lender may require as set forth in the HOME
Agreement referenced above.
The insurance canier providing the insurance shall be chosen by Borrower subject to approval by Lender;
provided that such approval shall not be unreasonably withheld. All insurance policies and renewals
thereof shall be in a form acceptable to Lender and shall include a standard mortgage clause in favor of
and in a form acceptable to Lender. Lender shall have the right to hold the policies and renewals thereof,
subject to the terms of any mortgage, deed of trust or other security agreement with a lien which has
priority over this Deed of Trust.
ln the event of loss, Bonower shall give prompt notice to the insurance carrier and Lender. Lender may
make proof of loss if not made promptly by Borrower.
lf the Property is abandoned by Borrower, or if Borrower fails to respond to Lender within 30 days from the
date notice is mailed by Lender to Borrower that the insurance canier offers to settle a claim for insurance
benefits, Lender is authorized to collect and apply the insurance proceeds at Lender's option either to
restoration or repair of the Property or to the sums secured by this Deed of Trust.
3.
Borrower shall keep the Property in good repair and shall not commit waste or permit impairment or
deterioration of the Property and shall comply with the provisions of any lease if this Deed of Trust is on a
leasehold. lf this Deed of Trust is on a unit in a condominium or a planned unit development,
Borrower shall perform all of Bonower's obligations under the declaration or covenants creating or
governing the condominium or planned unit development, the by-laws and regulations of the condominium
or planned unit development, and constituent documents, Borrower shall not permit overcrowded
conditions to exist as defined by the U.S. Department of Housing and Urban Development.
4. Protection of Lender's Securitv. lf Borrower fails to perform the covenants and agreements contained in
this Deed of Trust, or if any action or proceeding is commenced which materially affects Lende/s interest in
the Property, then Lender, at Lende/s option, upon notice to Bonower, may make such appearances,
disburse such sums, including reasonable attorneyls fees, and take such action as is necessary to protect
Lender's interest. lf Lender requires mortgage insurance as a condition of making the loan secured by this
Deed of Trust, Borrower shall pay the premiums required to maintain such insurance in effect until such
time as the requirement for such insurance terminates in accordance with Borrower's and Lender's written
agreement or applicable laws.
2v2
E
6.
Any amounts disbursed by Lender pursuant to this Paragraph 5 shall become additional
indebtedness of Bonower secured by this Deed of Trust. Unless Borrower and Lender agree to other
terms of payment, such amounts shall be payable upon notice from Lender to Borrower requesting
payment thereof. Nothing contained in this paragraph 5 shall require Lender to incur any expense or take
any action hereunder.
lnspection. Lender may make or cause to be made reasonable entries upon and inspections of the
Property, provided that Lender shall provide Borrower notice prior to any such inspection specifying
reasonable cause therefore related to Lender's interest in the Property.
Condemnation. The proceeds of any award or claim for damages, direct or consequential, in connection
with any condemnation or other taking of the Property, or part thereof, or for conveyance in lieu of
condemnation, are hereby assigned and shall be paid to Lender, subject to the terms of any mortgage,
deed of trust or other security agreement with a lien which has priority over this Deed of Trust.
Borrower Not Released: Forbearance Bv Lender Not a Waiver. Extension of the time for payment or
modification of amortization of the sums secured by this Deed of Trust granted by Lender to any successor
in interest of Borrower shall not operate to release, in any manner, the liability of the original Borrower and
Borrower's successors in interest. Lender shall not be required to commence
proceedings against such successor or refuse to extend time for payment or otherwise modify amortization
of the sums secured by this Deed of Trust be reason of any demand made by the original Borrower and
Borrower's successors in interest. Any forbearance by Lender in exercising any right or remedy hereunder,
or otherwise afforded by applicable law, shall not be waiver of or preclude the exercise of any such right of
remedy.
The covenants and
agreements herein contained shall bind, and the rights hereunder shall inure to the respective successors
and assignees of Lender and Borrower. All covenants and agreements of Borrower shall be joint and
several. Any borrower who co-signs this Deed of Trust, but does not execute the Note, (a) is co-signing
this Deed of Trust only to grant and convey that Borrower's interest in the Property of Trustee under the
terms of this Deed of Trust, (b) is not personally liable on the Note or under this Deed of Trust or the Note,
without that Borrower's consent and without releasing that Borrower or modifying this Deed of Trust as to
that Borrower's interest in the Property.
Transferabilitv. One of the inducements to Beneficiary for making the Loan is the identity of Borrower. The
existence of any interest in the Property other than the interests of Borrower and Beneficiary and any
encumbrance permitted in this Deed of Trust, even though subordinate to the security interest of
Beneficiary, and the existence of any interest in Borrower other than those of the present owners, would
impair the Property and the security interest of Beneficiary, and, therefore, except as provided herein or in
the Loan Documents, Borrower will not sell, convey, assign, transfer, alienate, or otherwise dispose of its
interest in the Property, either voluntarily or by operation of law, or agree to do so, without the prior written
consent of Beneficiary. Consent to one transaction by Beneficiary will not be deemed a waiver of the right
to require consent to further or successive transactions. lf Borrower is a corporation, any sale, transfer, or
disposition of fifty percent (50%) or mor€ of the voting interest of Bonower or of any entity that direetly or
indirectly owns or controls Borrower, including, without limitation, the parent company of Borrower, and the
parent company of the parent company of Bonower, will constitute a sale of the Property for purposes of
this article. lf Bonower is a partnership any change or addition of a general partner of Borrower, change of
a partnership interest of Borrower, or sale, transfer, or disposition of fifty percent (50%) or more of the
voting interest or partnership interest of any partner of Borrower or of any corporation, partnership or entity
l..o
tl
7.
L
9.
that directly or indirectly owns or controls any partner of Borrower, including, without limitation, each parent
company of a partner of Borrower and each parent company of any parent company of a partner of
Borrower, will constitute a sale of the Property for purposes of this section. lf Bonower is a limited liability
company, any change of the manager or any sale, transfer or disposition of fifty percent (50o/o) or more of
the partnership interests of Borrower , or disposition of fifty percent (50%) or more of the voting interest of
Borrower or of any corporation, partnership or entity that directly or indirectly owns or controls any member
of Borrower, including without limitations, each parent company of Borrower and each parent company of
any parent company of a member of Borrower, will constitute a sale of the Property for purposes of this
section. Any transaction in violation of this section will cause all lndebtedness, inespective of the maturity
dates, at the option of the Beneficiary and without demand or notice, immediately to become due, together
with any prepayment premium in accordance with the terms of the Note except as prohibited by law.
10. Notice. Except for any notice required under applicable law to be given in another manner, (a) any notice
to Borrower provided for in this Deed of Trust shall be given by delivering it or by mailing such notice by
certified mail addressed to Borrower at the Property Address or at such other address as Borrower may
designate by notice to Lender as provided herein, and (b) any notice to lender shall
be given by certified mail to Lender's address stated herein or to such other address as Lender may
designate by notice to Borrower as provided herein. Any notice provided for in this Deed of Trust shall be
deemed to have been given to Borrower or Lender when given in the manner designated herein.
11. Governinq Law: Severabilitv. The state and local laws applicable to this Deed of Trust shall be the laws of
the jurisdiction in which the Property is located. The foregoing sentence shall not limit the applicability of
Federal law to this Deed of Trust or if the Note conflicts with applicable law, such conflict shall not affect
other provisions of this Deed of Trust or the Note which can be given effect without
the conflicting provision, and to this end the provisions of this Deed of Trust and the Note are declared to
be severable. As used herein, "costs", "expenses", and "attorney's fees" include all sums to the extent not
prohibited by applicable law or limited herein.
12. Borrowe/s Copv. Bonower shall be furnished a conformed copy of the Note and of this Deed of Trust at
the time of execution or after recordation thereof.
NON-CONFORMING COVENANTS. Borrower and Lender further covenant and agree as follows:
13. Acceleration: Remedies. Upon Borrower's breach of any covenant or agreement of Borrower in this Deed
of Trust, including the covenants to pay when due any sums secured by this Deed of Trust, the Note or the
Program restrictions, Lender prior to acceleration shall give notice to Borrower as provided in paragraph 10
hereof specifying: (1) the breach; (2) the action required to cure such breach; (3) a date, not less than 10
days from the date notice is mailed to Borrower, by which such breach must be cured; and (4) that failure
to cure such breach on or before the date specified in the notice may result in acceleration of the sums
secured by this Deed of Trust and sale of the Property. The notice shall further inform Bonower of the right
to reinstate after acceleration and the right to bring a court action to assert the nonexistence of a default or
any other defense of Borrower to acceleration and sale. lf the breach is not cured on or before the date
specified in the notice, Lender, at Lende/s option may declare all of the sums secured by this Deed of
Trust to be immediately due and payable without further demand and may invoke the power of sale and
any other remedies permitted by applicable law. Lender shall be entitled to collect all reasonable costs and
expenses incurred in pursuing the remedies provided in this paragraph 13, including, but not limited to,
reasonable attorney's fees. lf Lender invokes the power of sale, Lender shall execute or cause Trustee to
execute a written notice of the occurrence of an event of default and of Lender's election to cause the
Property to be sold and shall cause such notice to be recorded in each county in which the Property or
¿le,
some part thereof is located. Lender or Trustee shall mail copies of such notice in the manner prescribed
by applicable law. Trustee shall give public notice of sale to the persons and in the manner prescribed by
applicable law. After the lapse of such time as may be required by applicable law, Trustee, without
demand on Borrower, shall sell the Property at public auction to the highest bidder at the time and place
and under the terms designated in the notice of sale in one or more parcels and in such order as Trustee
may determine.
Trustee may postpone sale of all or any parcel of the Property by public ennouncement at the time and
place of any previously scheduled sale. Lender or Lender's designee may purchase the Property at any
sale.
Trustee shall deliver to the purchaser Trustee's deed conveying the Property so sold without any covenant
or warranty, expressed or implied. The recitals in the Trustee's deed shall be prima facie evidence of the
truth of the statements made therein. Trustee shall apply the proceeds of the sale in the following order:
(a) to all reasonable costs and expenses of the sale, including, but not limited to, reasonable Trustee's and
attorney's fees and costs of title evidence; (b) to all sums secured by this Deed of Trust; and (c) the excess,
if any, to the person or persons legally entitled thereto.
14. Borrower's Riqhtto Reinstate. Notwithstanding Lender's acceleration of the sumssecured bythis Deed of
Trust due to Borrower's breach, Borrower shall have the right to have any proceedings begun by Lender to
enforce this Deed of Trust discontinued at any time prior to five days before sale of the Property pursuant
to the power of sale contained in this Deed of Trust or at any time prior to entry of a judgment enforcing this
Deed of Trust if: (a) Borrower pays Lender all sums which would be then due under this Deed of Trust and
the Note had no acceleration occurred; (b) Borrower cures all breaches of any other covenants or
agreements of Bonower contained in this Deed of Trust; (c) Borrower pays all reasonable expenses
incurred by Lender and Trustee in enforcing the covenants and agreements of Bonower in paragraph 13
hereof, including but not limited to, reasonable attorney's fees; and (d) Borrower takes such
action as Lender may reasonably require to assure that the lien of this Deed of Trust, Lende/s interest in
the Property and Borrower's obligation to pay the sums secured by this Deed of Trust shall continue
unimpaired. Upon such payment and cure by Borrower, this Deed of Trust and the obligations secured
hereby shall remain in fullforce and effect as if no acceleration had occurred.
15. Nonrecourse. Borrower shall not have any personal liability for repayment of the loan. The sole recourse
of the Lender under the Loan Documents for repayment of the Loan shall be the exercise of its rights
against the Property.
16. Withdrawal. Removal and/or Replacement. General partner of the Borrower pursuant to the terms of a
partnership agreement due to violation by a general partner of the terms of a partnership agreement, or a
voluntary withdrawal from a partnership by a general partner, and any transfer of limited partnership
interest or interests in the same, shall not constitute a default under any of the Loan Documents, and any
such actions shall not accelerate the maturity of the loan.
17. Lien of Deed of Trust. Beneficiary agrees that the lien of this Deed of Trust shall be subordinated to any
extended low-income housing commitment (as such term is defined in Section (42(hX6XB) of the internal
Revenue Code) (the "Extended Use Agreement") recorded against the Property, provided that such
Extended Use Agreement, by its terms, must terminate upon foreclosure under this Deed of Trust or upon
a transfer of the Property by instrument of lieu of foreclosure, in accordance with Section 42(hX6XE) of the
lnternal Revenue Code, subject to the limitations upon evictions, terminations of tenancies and increases in
gross rents of tenants of low-income units as provided in that Section.
Le L€
18. As additional security hereunder,
Borrower hereby assigns to Lender the rents of the Property, provided that Bonower shall, prior to
acceleration under paragraph 13 hereof or abandonment of the Property, have the right to collect and
retain such rents as they become due and payable.
Upon acceleration under paragraph 13 hereunder or abandonment of the Property, Lender, in person, by
agent or by judicially appointed receiver shall be entitled to enter upon, take possession of and manage the
Property and to collect the rents of the Property including those past due. All rents collected by Lender or
the receiver shall be applied first to premiums on receiver's bonds and reasonable attorney's fees, and then
to the sums secured by this Deed of Trust. Lender and the receiver shall be liable to account only for those
rents actually received.
19. Reconvevance. Upon payment of all sums secured by this Deed of Trust, Lender shall request Trustee to
reconvey the Property and shallsurrender this Deed of Trust, and all notes evidencing indebtedness
secured by this Deed of Trust to Trustee. Trustee shall reconvey the Property without warranty and without
charge to the person or persons legally entitled thereto. Such person or persons shall pay all costs of
recordation, if any.
20. Substitute Trustee. Lender at lende/s option, may from time to time, appoint a successor trustee to any
Trustee appointed hereunder by an instrument executed and acknowledged by Lender and recorded in the
Fresno County Recorder's Office. The instrument shall contain the name of the original Lender, Trustee
and Borrower, the book and page where this lnstrument is recorded and the name and address of the
successor trustee. The successor trustee shall, without conveyance of the Property, succeed to all the
title, powers and duties conferred upon the Trustee herein and by applicable law. This procedure for
substitution of trustee shall govern to the exclusion of all other provisions for substitution,
21. Statement of Obliqation. Lender may collect a fee not to exceed $50 for furnishing the statement of
obligation as provided by Section 2943 of the Civil Code of California.
22. Event of Default. Prior to declaring or taking any remedy permitted under Loan Documents, (where
applicable) Borrower's limited partners shall have an additional period of not less than thirty (30) days to
cure such alleged default. Notwithstanding the foregoing, in the case of a default that cannot with
reasonable diligence be remedied or cured within thirty (30) days, Borrower's limited partners shall have
such additional time as reasonably necessary to remedy or cure such default, but in no event more than
ninety (90) days from the expiration of the initial thirty (30) day period above, and if the Borrower's limited
partners reasonably believe that in order to cure such default, Borrower's limited partners must remove one
or both of Borrower's general partners in order to cure such default, Borrower's limited partners shall have
an additional (30) days following the effective date of such removal to cure such default. To the extent that
there is a conflict between this paragraph 22 and any remedy permitted by the HOME Agreement, Loan
Documents, or Loan, the terms of this paragraph 22 shall control.
The following events are each an "Event of Default":
(a) Default in the payment of any sum of principal or inte¡,est when due under the Note or any other sum
due under the Loan Documents.
(b) Failure to maintain insurance as provided in Section 2 hereof.
{-?-\
(c) The failure (without cure during the applicable period, if any, for cure) of any Borrower to observe,
perform, or discharge any obligation, term, covenant, or condition of any of the Loan Documents, any
agreement relating to the Property, or any agreement or instrument between any Loan Party and
Beneficiary.
(d) The assignment by Borrower, as lessor or sublessor, as the case may be, of the rents or the income of
the Property or any part of it (other than to Beneficiary) without first obtaining the written consent of
Beneficiary.
(e) The following events:
(i) the filing of any claim or lien against the Property or any party of it, whether or not the lien is prior to
this Deed of Trust, and the continued maintenance of the claim or lien for a period of thirty (30) days
without discharge, satisfaction, or adequate bonding in accordance with the terms of this Deed of
Trust;
(ii) the existence of any interest in the Property other than those of Borrower, Beneficiary, any tenants
of Bonower, and any one listed in a title exception approved by Beneficiary in writing; or
(iii) the sale, hypothecation, conveyance, or other disposition of the Property except with the express
written approval of Beneficiary, any of which will be an Event of Default because Borrower's
obligation to own and operate the Property is one of the inducements to Beneficiary to make the
Loan;
(f) Default under any agreement to which Borrower is a party, which agreement relates to the borrowing of
money by Borrower from Beneficiary.
(g) Any presentation or warranty made by any Loan Party or any other Person under this Deed of Trust or
in, under, or pursuant to the Loan Documents, is false or misleading in any material respect as of the
date on which the representation or warranty was made.
(h) Any of the Loan Documents, at any time after their respective execution and delivery and for any
reason, cease to be in full force or are declared null and void, or the validity or enforceability is
contested by Borrower or any stockholder or partner of Borrower, or Borrower denies that it has any or
further liability or obligation under any of the Loan Documents to which it is a party.
lf one or more Event of Default occurs and ís continuing, then Beneficiary may declare all the lndebtedness
to be due and the lndebtedness will become due without any further presentment, demand, protest, or
notice of any kind, and Beneficiary may:
(i) in person, by agent, or by a receiver, and without regard to the adequacy of security, the solvency of
Borrower, or the existence of waste, enter on and take possession of the Property or any party of it in
its own name or in the name of Trustee, sue for or otherwise collect the rents, issues, and profits, and
apply them, less costs and expenses of operation and collection, including reasonable attorneys'fees,
upon the lndebtedness, allin any o¡de¡ that Beneficiary many determine. The entering on and taking
possession of the Property, the collection of rents, issues, and profits, and the application of them will
not cure or waive any default or notice of default or invalidate any act done pursuant to the notice;
(ii) commence an action to foreclose this Deed of Trust in the manner provided by law for the foreclosure
of mortgages of real property;
u?
(iii) deliver to Trustee a written declaration of default and demand for sale, and a written notice of default
and election to cause the Property to be sold, which notice Trustee or Beneficiary will cause to be
filed for record;
(iv) with respect to any Personalty, proceed as to both the real and personal property in accordance with
Beneficiary's rights and remedies in respect of the Land, or proceed to sell the Personalty separately
and without regard to the Land in accordance with Beneficiary's rights and remedies; or
(v) exercise any of these remedies in combination or any other remedy at law or in equity.
24. Protection of Securitv.
lf an Event of Default occurs and is continuing, Beneficiary or Trustee, without notice to or demand upon
Borrower, and without releasing Borrower from any obligations or defaults may:
(a) enter on the Property in any manner and to any extent that either deems necessary to protect the
security of this Deed of Trust;
(b) appear in and defend any action or proceeding purporting to affect, in any manner, the Obligations or
the lndebtedness, the security of this Deed of Trust, or the rights or powers of Beneficiary or Trustee;
(c) pay, purchase, or compromise any encumbrance, charge, or líen that in the judgment of Beneficiary or
Trustee is prior or superior to this deed of Trust; and
(d) pay expenses relating to the Property and its sale, employ counsel, and pay reasonable attorneys'fees.
Borrower agrees to repay on demand all sums expended by Trustee or Beneficiary pursuant to this section
with interest at the Note Rate of lnterest, and those sums, with interest, will be secured by this Deed of
Trust.
25. Effect of Assionment.
The assignment rents as provided herein will not impose on Beneficiary any duty to produce rents, issues,
or profits from the Property, or cause Beneficiary to be:
(a) a "mortgage-in-possession" for any purpose;
(b) responsible for performíng any of the obligations of the lessor under any of the Leases; or
(c) responsible for any waste committed by lessees or any other parties, any dangerous or defective
condition of the Property, or any negligence in the management, upkeep, repair, or control of the
Property.
Beneficiary will not be liable to Borrower or any other par:ty as a consequence of the exercise of the rights
granted to Beneficiary under this assignment or the failure of Beneficiary to perform any obligation of
Borrower arising under Leases.
lil
qq
lN WITNESS WHEREOF, Borrower has executed this Deed of Trust on the day and year set forth
above. By signing below, Borrower agrees to the terms and conditions as set forth above.
BORROWER
Southeast Fresno, RAD, LP, a California limited partnership
Name: Preston Prince
Title: Executive Director
(Attach notary certificate of acknowledgment)
1D
EXHIBTT *A''
To Deed of Trust
The Property is located at 4216 E. Hamilton Avenue, Fresno, CA 93702.
Real property in the City of Fresno, County of Fresno, State of California, described as follows:
LOTS 7, 8, 9, 10, 16, 17 AND THE EAST HALF OF LOT 18 OF GORDONDALE, ACCORDING TO THE MAP
RECORDED IN BOOK 8 OF PLATS, PAGE 45 IN THE CITY OF FRESNO, COUNTY OF FRESNO, STATE
OF CALIFORNIA.
EXCEPTING THEREFROM THE WEST 10 FEET OF SAID LOT 7 CONVEYED TO THE COUNTY OF
FRESNO, BY GRANT DEED RECORDED JUNE 13, 1967 IN BOOK 5448, PAGE 173 OF OFFICIAL
RECORDS OF FRESNO COUNTY.
APN : 47 1 -21 1 -01T, 47 I -21 2-011 and portion ol 47 1 -220-0 1 T
The Property is located at 510 S. Peach Avenue, Fresno, C493727.
Real property in the City of Fresno, County of Fresno, State of California, described as follows:
PARCEL B OF PARCEL MAP NO. 77.54 ACCORDING TO THE MAP THEREOF RECORDED IN BOOK 27
PAGE 85 OF PARCEL MAPS, RECORDS OF SAID COUNTY.
APN: 463-050-22
ts\\
The following is a copy of provisions (1) to (14), inclusive, of the fictitious deed of trust, recorded in
each county in California, as stated in the foregoing Deed of Trust and incorporated by reference in
said Deed of Trust as being a part thereof as if set forth at length therein
To Protect the Security of This Deed of Trust, Trustor (herein "Borrower") Agrees:
(1) To keep said property in good condition and repair, not to remove or demolish any building
thereon, to complete or restore promptly and in good and workmanlike manner any building which
may be constructed, damaged or destroyed thereon and to pay when due all claims for labor
performed and materials furnished therefor, to comply with all laws affecting said property or requiring
any alterations or improvements to be made thereon, not to commit or permit waste thereof, not to
commit, suffer or permit any act upon said property in violations of law to cultivate, irrigate, fertilize,
fumigate, prune and do all other acts which from the character or use of said property may be
reasonably necessary, the specific enumerations herein not excluding the general.
(2) To provide maintain and deliver to Beneficiary fire insurance satisfactory to and with loss payable
to Beneficiary. The amount collected under any fire or other insurance policy may be applied by
Beneficiary upon indebtedness secured hereby and in such order as Beneficiary may determine, or at
option of Beneficiary the entire amount so collected or any part thereof may be released to Borrower.
Such application or release shall not cure or waive any default or notice of default hereunder or
invalidate any act done pursuant to such notice.
(3) To appear in and defend any action or proceeding purporting to affect the security hereof or the
rights or powers of Beneficiary or Trustee, and to pay all costs and expenses, including cost of
evidence of title and attorney's fees in a reasonable sum, in any such action or proceeding in which
Beneficiary or Trustee may appear, and in any suit brought by Beneficiary to foreclose this Deed of
Trust.
(4) To pay at least ten days before delinquency all taxes and assessments affecting said property,
including assessments on appurtenant water stock, when due, all encumbrances, charges and liens,
with interest, on said property or any part thereof, which appear to be prior or superior hereto, all
costs, fees and expenses of this Trust.
Should Borrower fail to make any payment or to do any act as herein provided, then Beneficiary or
Trustee, but without obligation so to do and without notice to or demand upon Borrower and without
releasing Borrower from any obligation hereof, may make or do the same in such manner and to such
efent as either may deem necessary to protect the security hereof Beneficiary or Trustee being
authorized to enter upon said property for such purposes; appear in and defend any action or
proceeding purporting to atfect the security hereof or the rights or powers of Beneficiary or Trustee,
pay, purchase, contest or compromise any encumbrance, charge or lien which in the judgment of
either appears to be prior or superior hereto, and in exercising any such powers, pay necessary
expenses, employ counsel and pay his reasonable fees.
(5) To pay immediately and without demand all sums so expended by BenefTciary or Trustee, with
interest from date of expenditure at the amount allowed by law in effêct at the date hereôf, ând to pay
for any statement provided for by law in effect at the date hereof regarding the obligation secured
hereby any amount demanded by the Beneficiary not to exceed the maximum allowed by law at the
time when said statement is demanded.
(6) That any award of damages in connection with any condemnation for public use of or injury to said
property or any part thereof is hereby assigned and shall be paid to Beneficiary who may apply or
1r
release such moneys received by him in the same manner and with the same effect as above
provided for disposition of proceeds of fire or other insurance.
(7) That by accepting payment of any sum secured hereby after its due date, Beneficiary does not
waive his rights either to require prompt payment when due of all other sums so secured or to declare
default for failure so to pay.
(8) That at any time or from time to time, without liability therefor and without notice, upon written
request of Beneficiary and presentation of this Deed and said Note for endorsement, and without
affecting the personal liability of any person for payment of the indebtedness secured hereby, Trustee
may reconvey any part of said property, consent to the making of any map or plot thereof; join in
granting any easement thereon; or join in any extension agreement or any agreement subordinating
the lien or charge hereof.
(9) That upon written request of Beneficiary state that all sums secured hereby have been paid, and
upon surrender of this Deed and said Note to Trustee for cancellation and retention and upon
payment of its fees, Trustee shall reconvey, without warranty, the property then held hereunder. The
recitals in such reconveyance of any matters or facts shall be conclusive proof of the truthfulness
thereof. The grantee in such reconveyance may be described as "The person or persons legally
entitled thereto "Five years after issuance of such full reconveyance, Trustee may destroy said note
and this Deed (unless directed in such request to retain them).
(10) That as additional security, Borrower hereby gives to and confers upon Benefïciary the right,
power and authority, during the continuance of these Trusts, to collect the rents, issues and profits of
said property, reserving unto Borrower the right, prior to any default by Borrower in payment of any
indebtedness secured hereby or in performance of any agreement hereunder, to collect the rents,
issues and profits of said property, reserving unto Borrower the right, prior to any default by Borrower
in payment of any indebtedness secured hereby or in performance of any agreement hereunder, to
collect and retain such rents, issues and profits as they become due and payable. Upon any such
default, Beneficiary may at any time without notice, either in person , by agent, or by a receiver to be
appointed by a court, and without regard to the adequacy of any security for the indebtedness hereby
secured, enter upon and take possession of said property or any part thereof, in his own name sue
for or otherwise collect such rents, issues and profits, including those past due and unpaid, and apply
the same, less costs and expenses of operation and collection, including reasonable attorney's fees.
Upon any indebtedness secured hereby, and in such order as Beneficiary may determine. The
entering upon and taking possession of said property, the collection of such rents, issues and profits
and the application thereof as aforesaid, shall not cure or waive any default or notice of default
hereunder or invalidate any act done pursuant to such notice.
(11) That upon default by Borrower in payment of any indebtedness secured hereby or in
performance of any agreement hereunder. Beneficiary may declare all sums secured hereby
immediately due and payable by delivery to Trustee of written declaration of default and demand for
sale and of written notice of default and of election to cause to be sold said property which notice
Trustee shall cause to be filed for record. Beneficiary also shall deposit with Trustee this Deed, said
note and all documents evidenciñg expenditures secured hereby.
After the lapse of such time as may then be required by law following the recordation of said notice of
default, and notice of sale having been given as then required by law, Trustee, without demand on
Borrower, shall sell said property at the time and place fixed by it in said notice of sale, either as a
whole or in separate parcels, and in such order as it may determine, at public auction to the highest
bidder for cash in lawful money of the United States, payable at time of sale. Trustee may postpone
*\)
sale of all or any portion of said property by public announcement at such time and place of sale, and
from time to time thereafter may postpone such sale by public announcement at the time fixed by the
preceding postponement Trustee shall deliver to such purchaser its deed conveying the property so
sold, but without any covenant or warranty, express or implied. The recitals in such deed of any
matters or facts shall be conclusive proof of the truthfulness thereof. Any person, including Borrower,
Trustee, or Beneficiary as hereinafter defined, may purchase at such sale.
After deducting all costs, fees and expenses of Trustee and of this Trust, including cost of evidence of
title in connection with sale, Trustee shall apply the proceeds of sale to payment of all sums
expended under the terms hereof, not then repaid, with accrued interest at the amount allowed by law
in effect at the date hereof, all other sums then secured hereby, and the remainder, if any, to the
person or persons legally entitled thereto.
(12) Beneficiary, or any successor in ownership of any indebtedness secured hereby, may from time
to time, by instrument in writing, substitute a successor or successors to any Trustee named herein or
acting hereunder, which instrument, executed by the Beneficiary and duly acknowledged and
recorded in the office of the recorder of the county or counties where said property is situated, shall
be conclusive proof of proper substitution of such successor Trustee or Trustees, who shatl, without
conveyance from the Trustee predecessor, succeed to all its title, estate, rights, powers and duties.
Said instrument must contain the name of the original Borrower, Trustee and Beneficiary hereunder,
the book and page where this Deed is recorded and the name and address of the new Trustee.
(13) That this Deed applies to, inures to the benefit of, and binds all parties hereto, their heirs,
legatees, devisees, administrators, executors, successors and assigns. The term Beneficiary shall
mean the owner and holder, including pledgees, of the note secured hereby whether or not named as
Beneficiary herein in this Deed, whenever the context so requires ,the masculine gender includes the
feminine and/or neuter, and the singular number includes the plural.
(1a) That Trustee accepts this Trust when this Deed, duly executed and acknowledged, is made a
public record as provided by law. Trustee is not obligated to notify any party hereto of pending sale
under any other Deed of Trust or of any action or proceeding in which Borrower, Beneficiary or
Trustee shall be a party unless brought by Trustee.
DO NOT RECORD
REQUEST FOR FULL RECONVEYANCE
To be used only when note has been paid:
To Lawyers Title Company, Trustee: Dated
The undersigned is the legal owner and holder of all indebtedness secured by the within Deed of Trust. All sums secured
by said Deed of Trust have been fully paid and satisfied; and you are hereby requested and directed, on payment to you
of any sums owing to you under the terms of said Deed of Trust, to cancel all evidences of indebtedness, secured by said
Deed of Trust, delivered to you herewith together with said Deed of Trust, and to reconvey, without warranty, to the
parties designated by the terms of said Deed of Trust, the estate now held by you under the same.
MAIL RECONVEYANCE TO:
By
Do not lose or destroy this Deed of Trust OR THE NOTE which it secures. Both must be delivered tolhe Trustee for
cancellation before reconveyance will be made.
?'{
EXHIBIT '¡H" . EXEMPLAR DECLARATION OF RESTRICTIONS
Recorded at the Request of
and When Recorded Return to:
City of Fresno
Development and Resource Management Dept.
Housing and Community Development Division
2600 Fresno Street, Room 3070
Fresno, CA 93721-3605
(spAcE ABOVE TH|S L|NE FOR RECORDER'S USE ONLY)
The document is exempt from the payment of a recording fee in accordance with Govemment Code Secfions 6103 and 27383.
APN: 471-211-01T, 471-212-01I, and portion of 471-220-01T, and 463-050-227
DECLARATION OF RESTRICTIONS
THIS DECLARATION OF RESTRICTIONS, ("Declaration"), is executed as of this
day of 2013, by Southeast Fresno RAD, LP, a California limited partnership
("DECI-ARANT"), in favor of the CITY OF FRESNO, a Californía municipal corporation
('clrY').
WHEREAS, DECLARANT is the owner of the real estate in the county of Fresno,
state of California located a|4216 E. Hamilton Avenue, Fresno, California 93702 and 510
S. Peach Avenue, Fresno, California 93727 (A.P.N.: 471-211-01T, 471-212-01T, and
portion of 471-220-01T, and 463-050-22I, which is more particularly described in EXHIBIT
"Au - Property Description, attached hereto and made a part hereof, including the
improvements thereon (the "Property"); and
WHEREAS, pursuant to a certa¡n City of Fresno HOME Investment Partnerships
Agreement dated 2013, incorporated herein by reference ("HOME
Agreement") and instruments referenced therein, DECI-ARANT agrees to utilize, the CITY
agrees to provide, certain HOME funds from the United States Department of Housing and
Urban Development ("HUD"), to DECI-ARANT and DECLARANT agrees to rehabilitate the
Cedar Court Apartments and the lnyo Terrace Apartments as Affordable Low-lncome
housing, subject to the terms and conditions set forth in the HOME Agreement, and reserve
the unit for a Low-lncome household earning fifty percent (50%) to eighty percent (80%), or
below, of the area median income for the Fresno Metropolitan Statistical Area ('FMSA').
WHEREAS, the HOME regulations promulgated by HUD, including without limitation
24 C.F.R. 92.252; 24 and the HOME Agreement impose certa¡n affordability requirements
upon property owned by the DECLARANT, which affordability restrictions shall be
enforceable for a fifty-five (55) year period; and
WHEREAS, these restrictions are intended to bind the DECLARANT, and all
purchasers of the Property and their successors.
-1{
NOW THEREFORE, DECLARANT declares that the Property is held and will be
held, transferred, encumbered, used, sold, conveyed and occupied subject to the
covenants, restrictions, and limitations set forth in this Declaration, all of which are declared
and agreed to be ín furtherance of the Project. All of the restrictions, covenants and
limitations will run with the land and will be binding on all parties having or acquiring any
right, title or interest in the Property or any part thereof, will inure to the benefit of the ClTY,
and will be enforceable by it. Any purchaser under a contract of sale covering any right,
title or interest in any part of the Property, by accepting a deed or a contract of sale or
agreement of purchase, accepts the document subject to, and agrees to be bound by, any
and all restrictions, covenant, and limitations set forth in this Declaration commencing on
the date the DECI-ARANT is notified by the CITY that the Affordable Unit Homebuyer
information is has been entered into HUD's lntegrated Disbursement and lnformation
System (lDlS) as provided in the HOME Agreement, constituting the commencement of the
fifty-five (55) year Affordability Period.
1. Declarations. DECLARANT hereby declares that the Property is and shall be
subject to the covenants and restrictions hereinafter set forth, all of which are declared to
be in furtherance of the Project and the HOME Agreement, and are established and agreed
upon for the purpose of enhancing and protecting the value of the Property and in
consideration of the CITY entering into the HOME Agreement with the DECI-ARANT.
2. Restrictions. The following covenants and restrictions on the use and
enjoyment of the Property shall be in addition to any other covenants and restrictions
affecting the Property, and all such covenants and restrictions are for the benefit and
protection of the CITY and shall run with the Property and be binding on any future owner's
of the Property and inure to the benefit of and be enforceable by CITY. These covenants
and restrictions are as follows:
a. The DEC|ARANT for itself and its successor(s) on title covenants and
agrees that from the date the Project is entered into lDlS as complete, until the expiration
of the Affordability Period, it shall cause nine (9) of the Affordable Units to be used as
Affordable rental housing Units. The DECLARANT further agrees to file a recordable
document setting forth the Project Completion Date and Affordability Period when
determined by the CITY. Unless otherwise provided in the Agreement, the term Affordable
Housing shall include, without limitation, compliance with the following requirements:
i. Nondiscrimination. There shall be no discrimination against nor
segregation of any persons or group of persons on account of race, color, creed, religion,
sex, marital status, national origin, ancestry, or handicap in the sale, transfer, use,
occupancy, tenure, or enjoyment of any of the Property, nor shall DECLARANT establish or
permit any practice of discrimination or segregation with reference to the selection,
location, number, use or occupancy of owners or vendees of the Project and/or Property.
i¡. Principâl Résidènce. Each of the nine (9) HOME-assisted
Affordable Units within the Project upon the Property shall be leased only to eligible Low-
lncome households, who shall occupy Affordable Units as their principal resident. The
forgoing requirement that the Property tenants occupy the Affordable Units as their
principal residence does not apply to persons, other than natural persons, who acquire the
.!u
Property or portion thereof by foreclosure or deed in lieu of foreclosure or HUD qualified
entity that acquires the Property or portion thereof, with the consent of the CITY.
¡¡¡. lncome Requirements. A total of nine (9) Affordable Units may
be leased only to eligible households whose annual income at the time of initial occupancy
is not greater than fifty percent (50%) to eighty percent (80%) of the most recent annual
median income calculated and published by HUD for the FMSA applicable to such
household's size.
3. Enforcement of Restrictions. Without waiver or limitation, the CITY shall be
entitled to injunctive or other equitable relief against any violation or attempted violation of
any Covenant and Restriction.
4. Acceptance and Ratification. All present and future owners of the Property
and other persons claiming by, through, or under them shall be subject to and shall comply
with the Covenant and Restriction. The acceptance of a deed of conveyance to the
Property shall constitute an agreement that the Covenant and Restriction, as may be
amended or supplemented from time to time, are accepted and ratified by future owners,
tenant or occupant, and such Covenant and Restriction shall be a covenant running with
the land and shall bind any person having at any time any interest or estate in the Property,
all as though such Covenant and Restriction was recited and stipulated at length in each
and every deed, conveyance, mortgage or lease thereof.
Notwithstanding the foregoing, upon foreclosure by a lender or other transfer in lieu
of foreclosure, or assignment of an FHA-insured mortgage to HUD, the Affordability Period
shall be terminated unless the foreclosure or other transfer in lieu of foreclosure or
assignment recognizes any contractual or legal rights of public agencies, nonprofit
sponsors, or others to take actions that would avoid the termination of low-income
affordability. However, the requirements with respect to Affordable Unit shall be revived
according to their original terms, if during the original Affordability Period, the owner of
record before the foreclosure or other transfer, or any entity that includes the former owner
of those with-whom the former owner has or had formally, family or business ties, obtains
an ownership interest in the Project or the Property, the Affordability Period shall be revived
according to its originalterms.
5. Benefit. This Declaration shall run with and bind the Property for a term
commencing on the date Project information is entered into lDlS as complete, until the
expiration of the fifty-five (55) year Affordability Period. The failure or delay at any time of
CITY and/or any other person entitled to enforce this Declaration shall in no event be
deemed a waiver of the same, or of the right to enforce the same at any time or from time
to time thereafter, or an estoppel against the enforcement thereof.
6. Costs and Attornev's Fees. ln any proceeding arising because of failure of
DECLARANT or any future owner of the Property to comply with the Covenant and
Restriction required by this Declaration, as may be amended from time to time, the CITY
shall be entitled to recover its respective costs and reasonable attorney's fees incurred in
connection with such default or failure.
44
7. Waiver. Neither DECT ARANT nor any future owner of the Property may
exempt itself from liability for failure to comply with the Covenant and Restriction required in
this Declaration; provided however, that upon the transfer of the Property, the transferring
owner may be released from liability hereunder, upon the CIW's written consent of such
transfer, which consent shall not be unreasonably withheld, conditioned or delayed.
8. Severabilitv. The invalidity of the Covenant and Restriction or any other
covenant, restriction, condition, limitation, or other provision of thÍs Declaration shall not
impair or affect in any manner the validity, enforceability, or effect of the rest of this
Declaration and each shall be enforceable to the greatest extent permitted by law.
9. Pronouns. Any reference to the masculine, feminine, or neuter gender herein
shall, unless the context clearly requires the contrary, be deemed to refer to and include all
genders. Words in the singular shall include and refer to the plural, and vice versa, as
appropriate.
10. lnterpretation. The captions and titles of the various articles, sections,
subsections, paragraphs, and subparagraphs of this Declaration are inserted herein for
ease and convenience of reference only and shall not be used as an aid in interpreting or
construing this Declaration or any provision hereof.
11. Amendment. No amendment or modification of this Declaration shall be
permitted without the prior written consent of the CITY and DECI-ARANT.
12. Recordation. DECL-ARANT acknowledges that this Declaration will be filed of
record in the Office of the Recorder of County of Fresno, State of California.
13. Capitalized Terms. All capitalized terms used in this Declaration, unless
otherwise defined herein, shall have the meanings assigned to such terms in the HOME
Agreement.
14. Headinqs. The headings of the articles, sections, and paragraphs used in
this Declaration are for convenience only and shall not be read or construed to affect the
meaning or construction of any provision.
15. DECLARANT LIABILITY. The DECLARANT nor any of its general or limited
partners shall have any personal liability for the obligations under this Declaration. The
sole recourse of the CITY shall be exercised of its rights against the Property pursuant to
the Deed of Trust and Lender shall have no right to seek or recover any deficiency amount
from DECI-ARANT.
ilt
ilt
.P
lN WITNESS WHEREOF, DECLARANT has executed this Declaration of
Restrictions on the date first written above.
DECI.ARANT:
Southeast Fresno RAD, LP, a California limited partnership
Date:
Name: Preston Prince
Title: Executive Director
(Attach notary certifìcate of acknowledgment)
By:
?1
EXHIBIT "A''
To Declaration of Restrictions
The Property is located at 4216 E. Hamilton Avenue, Fresno, cA 93702.
Real property in the City of Fresno, County of Fresno, State of California, described as foltows:
LOTS 7, 8, 9, 10, 16, 17 AND THE EAST HALF OF LOT 18 OF GORDONDALE, ACCORDING TO
THE MAP RECORDED IN BOOK 8 OF PI.ATS, PAGE 45 IN THE CITY OF FRESNO, COUNTY OF
FRESNO, STATE OF CALIFORNIA.
EXCEPTING THEREFROM THE WEST 10 FEET OF SA]D LOT 7 CONVEYED TO THE COUNTYOF FRESNO, BY GRANT DEED RECORDED JUNE 13, 1967 IN BOOK 5448, PAGE 173 OF
OFFICIAL RECORDS OF FRESNO COUNTY.
APN: 471-211-01T,471-212-01t and portion of 471-220-01T
The Property is located at 510 s. Peach Avenue, Fresno, cAggr27.
Real property in the City of Fresno, County of Fresno, State of California, described as foilows:
PARCEL B OF PARCEL MAP NO. 77-54 ACCORDING TO THE MAP THEREOF RECORDED IN
BOOK 27 PAGE 85 OF PARCEL MAPS, RECORDS OF SAID COUNTY.
APN: 463-050-22
ßD
September 12, 2013
TO:
FROM:
Council Adoption : 9 I l2l20l3
Mayor Approval:
overnde ttequest:
YVONNE SPENCE,
City Clerk
, it' ûLt;ìti, FRisiit c^
SUBJECT: TRANSMITTAL OF COUNCI ACTION FOR APPROVAL OR VETO
At the Council meeting o'f 9112113, Council approved a $1.5 million HOME lnvestment
Partnerships Program Agreement with Southeast Fresno FI,AD, LP, for rehabilitation of
several properties, ltem No. 2D, by the following vote:
Ayes :Noes :Absent :Abstain :
Baines, Brandau, Caprioglio, Olivier, Quintero, Xiong
Brand
None
None
Please indicate either your formal approval or veto by completing the following sections and
executing and dating your action. Please file the completed memo with the Clerk's office on
oi before September 23,2013. ln computing the ten day period required by Charter, the first
day has been excluded and the tenth day has been included unless the 1Oth day is a
Saturday, Sunday, or holiday, in which case it has also been excluded. Failure to file this
memo with the Clerk's office within the required time limit shall constitute approval of the
ordinance, resolution or action, and it shall take effect without the Mayor's signed approval.
Thank you.
RETURN:
for the following reasons: (Written objections are required by Charter; attach
additional sheets if necessary.)
Date:
Date:COUNCIL OVERRIDE AGTION:
Ayes :
Noes
Absent
Abstain