HomeMy WebLinkAboutHousing Authority - HOME - 375 and 380 N Park Ave - 2011RECORDED AT THE REQUEST OF
AND WHEN RECORDED RETURN TO:
City of Fresno
City Clerk's Office
No Fee — Govt. Code 6103
2600 Fresno Street, Room 2133
Fresno, CA 93721
(SPACE ABOVE THIS LINE FOR RECORDER'S USE ONLY)
i�
r
c U
w�
This Agreement is recorded at the request and for the benefit of the City of Fresno and is exempt
cN from the payment of a recording fee pursuant to Government Code Section 6103 and 27383.
:.. .Y
CITY OF FRESNO
Mark Scott, City Manager
Date: � - '- //
HOME INVESTMENT PARTNERSHIPS PROGRAM AGREEMENT
by and between
CITY OF FRESNO,
a municipal corporation
MM
Housing Authority of the City of Fresno
a California Public Agency
regarding
"375 N. Park Avenue (APN: 459-143-03T) and
380 N. Park Avenue (APN: 459-144-23T)"
Low -Income Single -Family Housing Rehabilitation and Sale
Page 1 of 57
TABLE OF CONTENTS
RECITALS............................................................................................................................3
ARTICLE 1.
DEFINITIONS..................................................................................................4
ARTICLE2.
TERMS............................................................................................................7
ARTICLE 3.
GENERAL REPRESENTATIONS AND WARRANTIES OF DEVELOPER ....
8
ARTICLE 4.
HOME PROGRAM REPRESENTATION AND WARRANTIES BY
DEVELOPER........................................................................................................................9
ARTICLE 5.
COVENANTS AND AGREEMENTS OF DEVELOPER................................13
ARTICLE 6.
HOME PROGRAM FUNDS...........................................................................17
ARTICLE 7.
DEVELOPMENT AND REHABILITATION OF PROJECT ...........................18
ARTICLE 8.
PROJECT OPERATIONS.............................................................................23
ARTICLE 9.
INDEMNIFICATION AND INSURANCE.......................................................26
ARTICLE 10.
DEFAULT AND REMEDIES.......................................................................28
ARTICLE 11.
GENERAL PROVISIONS............................................................................30
ATTACHMENTS:
EXHIBIT A: PROPERTY DESCRIPTION
EXHIBIT B: PROJECT DESCRIPTION AND SCHEDULE
EXHIBIT C: EXEMPLAR DECLARATION OF RESTRICTIONS
EXHIBIT D: BUDGET
EXHIBIT E: EXEMPLAR CERTIFICATE OF COMPLETION
EXHIBIT F1: EXEMPLAR NOTE AND TEMPLATE RIDER TO DEED(S) OF TRUST
EXHIBIT F2: EXEMPLAR NOTE AND TEMPLATE RIDER TO DEED(S) OF TRUST
EXHIBIT G: GUIDE TO REHABILITATION STANDARDS
Page 2 of 57
HOME INVESTMENT PARTNERHIPS PROGRAM AGREEMENT
This HOME Investment Partnerships Program Agreement (hereinafter referred to as
the "Agreement') is entered into this, �e� �9, 2011, by and between the
CITY OF FRESNO, a municipal corporation, acting through its Development and Resource
Management Department — Housing and Community Development Division (hereinafter
referred to as the "CITY"), and the Housing Authority of the City of Fresno, a California
public agency (hereinafter referred to as "DEVELOPER").
RECITALS
WHEREAS, the CITY has received a HOME Investment Partnerships Program
(hereinafter referred to as "HOME Program") grant from the U.S. Department of Housing
and Urban Development (hereinafter referred to as "HUD"), under Title II of the Cranston -
Gonzalez National Affordable Housing Act of 1990, as amended (hereinafter referred to as
the "ACT'); and
WHEREAS, to advance the supply of Affordable Housing within the City of Fresno,
the CITY desires, among other things, to encourage investment in the affordable housing
market; and
WHEREAS, the Project will be constructed upon two HOME eligible parcels
(collectively "Property") located within the boundaries of the City of Fresno, owned by the
DEVELOPER, as more particularly described in the attached EXHIBIT "A"; and
WHEREAS, the DEVELOPER desires to rehabilitate the two (2) separate Affordable
Single -Family Housing Units currently located on the project Property to be sold as Low -
Income Housing and related on-site and off-site improvements, hereinafter referred to as
the "Project', as more particularly described in the Project Description and Schedule
attached hereto as EXHIBIT "B", incorporated herein; and
WHEREAS, to advance the supply of Affordable Housing within the City of Fresno,
the CITY desires to provide assistance to the Project in the total amount of One Hundred
Seventy Thousand Sixty Three Dollars and 00/100 ($170,063.00) in HOME Funding as an
assumable and partially forgivable Loan, for eligible HOME Project property rehabilitaton
costs, upon the terms and conditions in this Agreement, as further identified in EXHIBIT "D"
(Budget), to be secured by the underlying Property and the Affordable Housing covenants,
see attached Exhibit "F1" and "F2" Exemplar Notes (Project Loan) and the attached
EXHIBIT "C" Declaration of Restrictions, respectively; and
WHEREAS, the CITY has conducted an environmental review of the Project
pursuant to the National Environmental Policy Act ("NEPA"), resulting in a finding of
Categorical Exclusion according to the provisions of the NEPA (Environmental Assessment
No. H-2011-01) and the California Environmental Quality Act ("CEQA"), resulting in a
Categorical Exemption according to the provisions of CEQA (Environmental Assessment
No. H-2011-01); and
WHEREAS, the CITY has determined that this Agreement is in the best interests of,
and will materially contribute to, the Housing Element of the General Plan. Further, the
Page 3 of 57
CITY has found that the Project (i) will have a positive influence in the neighborhood and
surrounding environs, (ii) is in the vital and best interests of the CITY, and the health,
safety, and welfare of CITY residents, (iii) complies with applicable federal, state, and local
laws and requirements, (iv) will increase, improve, and preserve the community's supply of
Low -Income Housing available at affordable housing cost to persons and families of Low -
Income, as defined hereunder, (v) planning and administrative expenses incurred in pursuit
hereof are necessary for the production, improvement, or preservation of Low -Income
Housing, and (vi) will comply with any and all owner participation rules and criteria
applicable thereto; and
WHEREAS, on August 24, 2011, the Housing and Community Development
Commission of the City of Fresno reviewed this Agreement and recommended approval.
NOW, THEREFORE, IN CONSIDERATION of the above recitals, which recitals are
contractual in nature, the mutual promises herein contained, and for other good and
valuable consideration hereby acknowledge, the parties agree as follows:
ARTICLE 1. DEFINITIONS
The following terms have the meaning and content set forth in this Article wherever used in
this Agreement and the attached exhibits or attachments that are incorporated into this
Agreement by reference.
1.1. Acquisition means vesting of Property in fee title.
1.2. ADA means the Americans with Disabilities Act of 1990, as most recently
amended.
1.3. Affirmative Marketing means a good faith effort to attract eligible persons of
all racial, ethnic and gender groups, in the housing market area, to purchase the Housing
Units that are proposed for rehabilitation on the eligible Property, as hereinafter defined.
1.4. Affordable Housing means the proposed Affordable Housing Project Units,
consisting of two (2) separate single-family homes, each of which will be required to meet
the affordability requirements of this Agreement and 24 CFR 92.254 and which affordability
requirements shall run with the land for the Affordability Period subject to release as
provided in this Agreement.
1.5. Affordability Period means the thirty (30) year period commencing from the
date project and homebuyer information is entered into HUD's Integrated Disbursement
and Information System (IDIS) and the project is identified as complete in IDIS. The date
will be provided to DEVELOPER by the CITY.
1.6. Budget means the pro forma Budget (attached hereto as EXHIBIT 'D"), and any
changes thereto approved by the CITY's Housing and Community Development Division
Manager provided the total amount of HOME Funding allocated to the Project shall not be
increased without City Council approval,.
1.7. Certificate of Completion means that certificate issued, in the form attached
Page 4 of 57
as EXHIBIT "E" ("Certificate of Completion"), to DEVELOPER by the CITY evidencing
completion of each Project Unit rehabilitated on the Property for purposes of this
Agreement.
1.8. CFR means the Code of Federal Regulations.
1.9. Commencement of Rehabilitation means the time DEVELOPER or
DEVELOPER'S rehabilitation contractor begins substantial physical work of the
Project/each Project Unit on the Property, including, without limitation, delivery of materials
and any work, beyond maintenance of the Property in its status quo condition.
1.10. Declaration of Restrictions means the Declaration of Restrictions in the form
attached hereto as EXHIBIT "C", which shall be recorded against the Property concurrent
with the recordation of this Agreement, setting out the Affordable Housing covenants and
requirements of this Agreement which shall run with the land.
1.11. Deed of Trust means that/those Deed(s) of Trust (including security
agreement(s)) given by DEVELOPER as Trustor, to the CITY as beneficiary, and recorded
against the Property to ensure the Note(s), together with the Rider to Deed of Trust,
attached as Exhibits "F1" and "F2" and acceptable to the City Attorney, as well as any
amendments to, modifications of and restatements of said Deed of Trust, which Deed of
Trust shall be subordinated to the persons or entities that provide financing to the
Developer, or subsequent Homebuyer, for,the_Project per the Budget attached as EXHIBIT
"D". The terms of any such Deed of Trust are hereby incorporated into this Agreement by
this reference.
1.12. Eligible Costs means the HOME Program eligible property rehabilitation costs
funded by the Loan, consistent with the Budget attached as EXHIBIT "D", allowable under
24 CFR Part 92, as specified in 24 CFR 92.205 and 92.206, and not disallowed by 24 CFR
92.214, provided, however, that costs incurred in connection with any activity that is
determined to be ineligible under the Program by HUD or the CITY shall not constitute
Eligible Costs.
1.13. Event of Default shall have the meaning assigned to such term under Section
10.1 hereunder.
1.14. Family has the same meaning given that term in 24 CFR 5.403.
1.15. Hazardous Materials means any hazardous or toxic substances, materials,
wastes, pollutants or contaminants which are defined, regulated or listed as "hazardous
substances," "hazardous wastes," "hazardous materials," "pollutants," "contaminants" or
"toxic substances" under federal or state environmental and health safety laws and
regulations, including without limitation, petroleum and petroleum byproducts, flammable
explosives, urea formaldehyde insulation, radioactive materials, asbestos and lead.
Hazardous Materials do not include substances that are used or consumed in the normal
course of developing, operating or occupying a housing project, to the extent and degree
that such substances are stored, used and disposed of in the manner and in amounts that
are consistent with normal practice and legal standards.
Page 5 of 57
1.16. HOME Investment Partnerships Funds (also referred to in this Agreement as
HOME Funds) means the HOME Program monies constituting the Loan, in an amount not
to exceed the sum of One Hundred Seventy Thousand Sixty Three Dollars and 00/100
($170,063.00) used for HOME Program eligible property acquisition costs.
1.17. Household means one or more persons occupying a Unit in the proposed
Affordable Housing Project.
1.18. HUD means the United States Department of Housing and Urban
Development.
1.19. Loan means the assumable and partially forgivable Project Loan of HOME
Funds, in the total amount not to exceed the lesser of the sum of One Hundred Seventy
Thousand Sixty Three Dollars and 00/100 ($170,063.00) and the aggregate HOME
Program per unit cap (24 C.F.R. 92.250) for the two (2) HOME -assisted Units as
determined by the CITY made available by the CITY to the Project pursuant to this
Agreement, as more specifically described in the Budget and in the Promissory Notes
attached hereto as Exhibits "71" and "F2". The Loan shall be allocated $84,081.00 to APN:
459-143-03T and $85,982.00 to APN: 459-144-23T, as identified in the Budget, and shall
be payable in accordance with the terms of the Notes, shall be secured by a Deed of Trust
on each parcel constituting the Property, and shall be subject to the Rider to Deed of Trust
attached to the Exhibits "F1" and "72" Exemplar Notes.
1.20. Loan Documents are collectively this Agreement, the Note(s), Deed (s) of
Trust, Declaration(s) of Restrictions and all related documents/instruments as they may be
amended, modified or restated from time to time along with all exhibits and attachments
thereto, relative to the Loan.
1.21. Low -Income Families means families whose annual income does not exceed
eighty percent (80%) of the median income for the Fresno, California area as determined
by HUD, except as HUD may establish income ceilings higher or lower than 80% of the
median for the area on the basis of HUD findings that such variations are necessary.
1.23. Note or Notes mean(s) the assumable, partially forgivable Project Note on
each parcel, substantially in the form attached hereto/incorporated herein as Exhibits "F" in
principal amount of $84,081.00 allocated to APN: 459-143-03T and $85,982.00 allocated to
APN: 459-144-23T, given by DEVELOPER as promissor, in favor of the CITY, as
promissee, evidencing the Loan and performance of the affordability and other covenants
and restrictions set forth in this Agreement, secured by a standard Deed of Trust creating a
lien upon the Property, naming the CITY as beneficiary and provided to the CITY no later
than the date of initial disbursement hereunder, as well as any amendments to,
modifications of and restatements of said Note consented to by CITY.
1.25. Program Income has the meaning provided in the HOME program including
24 CFR 92.503.
1.26. Project means the two (2) single-family low-income Affordable Housing Units
to be rehabilitated, marketed, and sold as Low -Income Housing, and related on-site and
Page 6 of 57
off-site improvements all as described in the Project Description and Schedule attached
hereto and incorporated herein as EXHIBIT "B", upon the Property as more particularly
described in EXHIBIT "A".
1.27. Project Completion Date means the date that the CITY shall have determined
that the Project has reached completion in accordance with this Agreement.
1.28. Proiect Schedule means the schedule for completion of the Project included
within the EXHIBIT "B" Project Description and Schedule.
1.29. Property means the vacant, unimproved DEVELOPER -owned HOME
Program eligible property located at 375 N. Park Avenue (APN: 459-143-03T) and
380 N. Park Avenue (APN: 459-144-23T), Fresno, California, more specifically described in
the attached EXHIBIT "A", to be developed as a low-income housing project as provided
herein.
1.30. Unit means each of the two (2) single-family homes rehabiltiated upon the
Property and preserved as Affordable Housing for the duration of the Affordability Period.
ARTICLE 2. TERMS
2.1 Loan of HOME funds. The CITY agrees to provide the Loan of HOME Funds
to the DEVELOPER in an amount not to exceed One Hundred Seventy Thousand Sixty
Three Dollars and 00/100 ($170,063.00) under the terms and conditions provided in this
Agreement. The HOME Funds shall only be used for payment of HOME eligible costs.
The Loan shall be assignable as provided in this Agreement and the Note(s).
2.2 Loan Documents. The DEVELOPER shall execute and deliver to the CITY
the Loan Documents including the Note(s), and notarized Deed(s) of Trust, for recordation
against the Property.
2.3 Term of Agreement. This Agreement is effective upon the date first above
and shall remain in force for the duration of the longer of the Affordability Period and the
Loan unless earlier terminated as provided herein, subject to obligations that expressly
survive. It is understood and agreed upon, however, that if for any reason this Agreement
should be terminated in whole or in part as provided hereunder, without default, by
DEVELOPER prior to disbursement of HOME Program Funding hereunder, the CITY
agrees to record a Notice of Cancellation regarding this Agreement, upon the written
request of DEVELOPER.
2.4 Loan Repayment and Maturity. The Loan will be due and payable in
accordance with the Note(s) and not later then the maturity date provided in the Note(s).
2.5 Incorporation of Documents. The DEVELOPER proposal dated July 25, 2011
and the CITY Council approved Minutes of , 2011, approving this
Agreement, the Loan Documents, the Act and HUD regulations at 24 CRF Part 92, and all
exhibits, attachments, documents and instruments referenced herein, as now in effect and
as may be amended from time to time, constitute part of this Agreement and are
incorporated herein by reference. All such documents have been provided to the parties
Page 7 of 57
herewith or have been otherwise provided to/procured by the parties and reviewed by each
of them prior to execution hereof.
2.6 Covenants of DEVELOPER. The DEVELOPER for itself and its
agents/assigns covenants and agrees to comply with all the terms and conditions of this
Agreement and the requirements of 24 CFR Part 92.
ARTICLE 3. GENERAL REPRESENTATIONS AND WARRANTIES OF DEVELOPER
3.1 Existence and Qualification. The DEVELOPER represents and warrants as
of the date hereof, that DEVELOPER is a duly organized public agency. DEVELOPER has
the requisite power, right, and legal authority to execute, deliver and perform its obligations
under this Agreement and has taken all actions necessary to authorize the execution,
delivery, performance, and observance of its obligations under this Agreement. This
Agreement, when executed and delivered, shall constitute the legal, valid and binding
obligations of the DEVELOPER enforceable against the DEVELOPER in accordance with
its respective terms, except as such enforceability may be limited by (a) bankruptcy,
insolvency, fraudulent, conveyance, reorganization, moratorium, or other similar laws of
general applicability affecting the enforcement of creditors' rights generally, and (b) the
application of general principles of equity without the joinder of any other party.
3.2 No Litigation Material to Financial Condition. The DEVELOPER represents
and warrants as of the date hereof that, except as disclosed to and approved by CITY in
writing, no litigation or administrative proceeding before any court or governmental body or
agency is now pending, nor, to the best of DEVELOPER'S knowledge, is any such litigation
or proceeding now threatened, or anticipated against DEVELOPER that, if adversely
determined, would have a material adverse effect on the financial condition, business, or
assets of DEVELOPER or on the operation of the Project.
3.3 No Conflict of Interest. The DEVELOPER represents and warrants as of the
date hereof that no official, officer, agent, or employee of the CITY directly or indirectly
owns or controls any interest in DEVELOPER, and no person, directly or indirectly owning
or controlling any interest in DEVELOPER, is an official, officer, agent, or employee of the
CITY.
3.4 No Legal Bar. The DEVELOPER represents and warrants as of the date
hereof that the execution, delivery, performance, or observance by DEVELOPER of this
Agreement will not, to the best of DEVELOPER'S knowledge, materially violate or
contravene any provisions of: (a) any existing law or regulation, or any order of decree of
any court, governmental authority, bureau, or agency; (b) governing documents and
instruments of DEVELOPER; or (c) any mortgage, indenture, security agreement, contract,
undertaking, or other agreement or instrument to which DEVELOPER is a party or that is
binding on any of its properties or assets, the result of which would materially or
substantially impair DEVELOPER'S ability to perform and discharge its obligations or its
ability to complete the Project under this Agreement.
3.5 Assurance of Governmental Approvals and Licenses. DEVELOPER
represents and warrants, as of the date hereof, that DEVELOPER has obtained and, to the
best of DEVELOPER'S knowledge, is in compliance with all federal, state, and local
Page 8 of 57
governmental reviews, consents, authorizations, approvals, and licenses presently required
by law to be obtained by DEVELOPER for the Project.
ARTICLE 4. HOME PROGRAM REPRESENTATION AND WARRANTIES BY
DEVELOPER
DEVELOPER, for itself and its development team, represents and warrants that
4.1 Affirmative Marketing. The DEVELOPER warrants, covenants and agrees
that it shall comply with all affirmative marketing requirements, including without limitation,
those set out at 24 CFR 92.350, 24 CFR 92.351, in order to provide information and
otherwise attract eligible persons from all racial, ethnic and gender groups in the housing
market in the sale of Project Units. DEVELOPER shall be responsible for complying with
the CITY'S "Affirmative Marketing Policy" document, incorporated herein, as amended from
time to time. DEVELOPER shall maintain records of actions taken to affirmatively market
units constructed in the future, and to assess the results of these actions.
4.2 Availability of HOME Funds. The DEVELOPER understands and agrees that
the availability of HOME Funds is subject to the control of HUD, or other federal agencies,
and should said Funds be encumbered, withdrawn or otherwise made unavailable to the
CITY, whether earned by or promised to DEVELOPER, and/or should CITY in any fiscal
year hereunder fail to allocate said Funds, the CITY shall not provide said Funds unless
and until they are made available for payment to the CITY by HUD and the CITY receives
and allocates said Funds. No other funds owned or controlled by the CITY shall be
obligated under this Agreement.
4.3 Compliance with Agreement. The DEVELOPER warrants, covenants and
agrees that, in accordance with the requirements of 24 CFR 92.254 and 24 CFR Part 85,
upon any uncured default by DEVELOPER within the meaning of Article 10 of this
Agreement, the CITY may suspend or terminate this Agreement and all other agreements
with DEVELOPER without waiver or limitation of rights/remedies otherwise available to the
CITY.
4.4 Conflict of Interest. The DEVELOPER warrants, covenants and agrees that it
shall comply with the Conflict of Interest requirements of 24 CFR 92.356 including, without
limitation, that no officer, employee, agent or consultant of DEVELOPER may occupy a
Project Unit. DEVELOPER understands and acknowledges that no employee, agent,
consultant, officer or elected official or appointed official of the CITY, who exercises or has
exercised any functions or responsibilities with respect to the Project, or who is in a position
to participate in a decision making process or gain inside information with regard to these
activities, may obtain a financial interest or benefit from the Project, or have an interest in
any contract, subcontract or agreement with respect thereto, or the proceeds thereunder,
either for him or herself or for anyone with which that person has family or business ties,
during his or her tenure or for one year thereafter. To the extent provided at 24 CFR
92.356(f), no owner, developer or sponsor of the Project, or officer, employee, agent or
consultant thereof, may occupy a Project Unit.
4.5 Rehabilitation Standards. DEVELOPER shall rehabilitate the proposed
housing units assisted under this Agreement in compliance with all applicable local codes,
Page 9 of 57
ordinances and zoning requirements in effect at the time of issuance of Certification of
Completion. In addition, the DEVELOPER will follow the City's "Guide to Rehabilitation
Standards", as attached in Exhibit G. In the absence of a local code for rehabilitation,
DEVELOPER agrees to comply with the applicable standards identified in 24 CFR 92.251.
4.6 Covenants and Restrictions to Run with the Land. The CITY and
DEVELOPER expressly warrant, covenant and agree to ensure that the covenants and
restrictions set forth in this Agreement are recorded and will run with the land, provided,
however, that, consistent with the Loan Documents, CITY may release said covenants and
restrictions only upon recapture of all HOME funding allocated to the Unit(s) by the CITY.
DEVELOPER further warrants, covenants and agrees to ensure that the covenants and
restrictions set forth herein shall run in favor of the CITY.
A. The CITY and DEVELOPER hereby declare their understanding and
intent that the covenants and restrictions set forth herein directly benefit the land (a) by
enhancing and increasing the enjoyment and ownership of the proposed Project by certain
Low -Income Families, and (b) by making possible the obtaining of advantageous financing
for rehabilitation.
B. The DEVELOPER covenants and agrees that it shall cause the two (2)
of the Project Units to be sold as Affordable Housing to Low -Income Families.
C. Without waiver or limitation, the CITY shall be entitled to injunctive or
other equitable relief against any violation or attempted violation of any covenants and
restrictions, and shall, in addition, be entitled to damages available under law or contract
for any injuries or losses resulting from any violations thereof.
D. The failure or delay at any time of the CITY or any other person
entitled to enforce any such covenants or restrictions shall in no event be deemed a waiver
of the same, or of the right to enforce the same at any time or from time to time thereafter,
or an estoppel against the enforcement thereof.
4.7 Displacement of Persons. The DEVELOPER warrants, covenants and
agrees that pursuant to 24 CFR 92.353, it will take all reasonable steps to minimize the
displacement of any persons (families, individuals, businesses, nonprofit organizations and
farms). The parties acknowledge and agree that the Property is vacant.
4.8 Initial Income Certification. The DEVELOPER warrants, covenants and
agrees that it shall comply with the procedures for income determinations at 24 CFR
92.203. DEVELOPER shall obtain, complete and maintain on file, immediately prior to
initial occupancy, income certifications from each of the two (2) Affordable Project Unit's
Household. DEVELOPER shall make a good faith effort to verify that the income provided
by an applicant or occupying Household in an income certification is accurate by taking one
or more of the following steps as part of the verification process: (1) obtain a pay stub for
the most recent pay period; (2) obtain an income verification form from the applicant's
current employer; (3) obtain an income verification form from the Social Security
Administration and California Department of Social Services if the applicant receives
assistance from either of such agencies; (4) obtain an income tax return for the most recent
tax year, or (5) if the applicant is unemployed and has no such tax return, obtain another
Page 10 of 57
form of independent verification. Copies of household income certification and verification
must be available for review and approval by the CITY prior to the close of escrow and the
transfer of title to the low-income homebuyer. DEVELOPER further warrants, covenants
and agrees that it shall cooperate with the CITY in the CITY'S income certification/
affordability monitoring activities at the time subsequent to initial transfer of the Unit
Property.
4.9 Lead -Based Paint. The DEVELOPER warrants, covenants and agrees that it
shall comply with all applicable requirements of the Lead -Based Paint Poisoning
Prevention Act of 42 U.S.C. 4821 et seq., 24 CFR Part 35 including the HUD 1012 Rule,
and 24 CFR 982.4010), including any amendments thereto and Environmental Protection
Agency (EPA) certification requirements under the Toxic Substances Control Act, in the
Affordable Housing Project. These requirements apply to all units and common areas in
the Affordable Housing Project. DEVELOPER shall incorporate or cause incorporation of
this provision in all contracts and subcontracts for work performed on the Project, which
involve the application of paint. DEVELOPER shall be responsible for all disclosure,
inspection, testing, evaluation, control and abatement activities.
4.10 Minority Outreach Activities. The DEVELOPER warrants, covenants and
agrees that it shall comply with all federal laws and regulations described in Subpart H of
24 CFR Part 92, including, without limitation, any requirement that DEVELOPER comply
with the CITY'S minority outreach program.
4.11 Other Laws and Regulations. The DEVELOPER warrants, covenants and
agrees that, in addition to complying with the federal laws and regulations already cited in
this Agreement, DEVELOPER has reviewed, and shall comply with, all other federal laws
and regulations that apply to the HOME Program, including, without limitation,
requirements of 24 CFR 58.6 and the Flood Disaster Protection Act of 1973, as amended
(42 U.S.C. 4001-4128) and the following:
A. The DEVELOPER does not intend to use any financing that is secured
by a mortgage insured by HUD in connection with the Project as part of its acquisition
and/or rehabilitation of this Project.
B. The Project is not located in a tract identified by the Federal
Emergency Management Agency as having special flood requirements.
C. The Project requirements, Subpart F of 24 CFR Part 92, as applicable
and in accordance with the type of Project assisted, including, but not limited to, the limit on
per-unit subsidy amount at 24 CFR 92.250.
D. The property standards at 24 CFR 92.251
E. The Project "Labor" requirements, as applicable, of 24 CFR 92.354
including Davis Bacon prevailing wage requirements (40 U.S.C. 276a - 276a-7), as
supplemented by Department of Labor regulations (29 CFR Part 5).
F. The provisions of Section 102 and 107 of the Contract Work Hours and
Safety Standards Act (40 U.S.C. 327-333), as supplemented by Department of Labor
Page 11 of 57
Regulations (29 CFR Part 5), in regards to the rehabilitation and management of the
proposed Project.
G. The DEVELOPER and its contractors, subcontractors and service
providers for the Project, shall comply with all applicable local, state and federal
requirements concerning equal employment opportunity, including compliance with E.O.
11246, "Equal Employment Opportunity," as amended by E.O. 11375, "Amending
Executive Order 11246 Relating to Equal Employment Opportunity," and as supplemented
by regulations at 41 CFR part 60, "Office of Federal Contract Compliance Programs, Equal
Employment Opportunity, Department of Labor."
H. The provisions of the Copeland "Anti -Kickback" Act (18 U.S.C. 874), as
supplemented by Department of Labor regulations (29 CFR part 3, "Contractors and
Subcontractors on Public Building or Public Work Financed in Whole or in Part by Loans or
Grants from the United States"),
I. The provisions of the Clean Air Act (42 U.S.C. 7401 et seq.) and the
Federal Water Pollution Control Act (33 U.S.C. 1251 et seq.), as amended.
J. The provisions of the Byrd Anti -Lobbying Amendment (31 U.S.C.
1352).
K. The provision of E.O.s 12549 and 12689, "Debarment and
Suspension," as set forth at 24 CFR part 24.
L. The provisions of the Drug -Free Workplace Act of 1988 (42 U.S.C.
701), in accordance with the Act and with HUD's rules at 24 CFR part 24, subpart F.
M. Title 8 of the Civil Rights Act of 1968 PL. 90-284.
N. Executive Order 11063 on Equal Opportunity and Housing.
O. Section 3 of the Housing and Urban Development Act of 1968.
P. The Housing and Community Development Act of 1974.
Q. Clean Water Requirements 33 U.S.C. 1251.
R. Civil Rights Requirements, 29 U.S.C. Section 623, 42 U.S.0 Section
2000, 42 U.S.0 Section 6102, 42 U.S.C. Section 12112, 42 U.S.0 Section 12132, 49
U.S.C. Section 5332, 29 CRF Part 1630, 41 CFR Parts 60 et. seq.
4.12 Religious Organizations and Faith Based Activities. DEVELOPER warrants,
covenants and agrees that it shall not engage in any prohibited activities described in 24
CFR 92.257.
4.13 Reporting Requirements. The DEVELOPER warrants, covenants and agrees
that it shall submit performance reports to the CITY as required hereunder. Furthermore,
the DEVELOPER agrees to provide, at the sole cost of the DEVELOPER, annual audited
Page '12 of 57
Financial Statements for the Project expenses and ongoing financial transactions which
occur as a result of this Agreement as required hereunder. The DEVELOPER agrees to
account for the expenditure of HOME Funds using generally accepted accounting
principals, which financial documentation shall be made available to the CITY and HUD
upon their respective written request(s).
4.14 Housing Affordability. The DEVELOPER warrants, covenants and agrees
that the Project will meet the Affordable Housing, income targeting and other requirements
of 24 CFR 92.254 upon sale of the two (2) homes to eligible Low -Income homebuyers,
except upon foreclosure by a lender or transfer in lieu of foreclosure following default under
a Deed of Trust. DEVELOPER shall return to the City all HOME funds disbursed upon
DEVELOPER'S failure to comply with this section 4.14, without limitation on City's other
remedies.
4.15 Terminated Proiects(s). The DEVELOPER understands and agrees that, if
the Project is terminated before completion, either voluntarily or otherwise, such constitutes
an ineligible activity and the CITY, without waiver or limitation upon other right and
remedies, will not be required to provide any further HOME Program assistance funding to
the Project Units and the City may seek available relief.
ARTICLE 5. COVENANTS AND AGREEMENTS OF DEVELOPER.
The DEVELOPER covenants and agrees to the following, for the entire term of the
Agreement.
5.1 Adequate Repair and Maintenance. The DEVELOPER during its time on title
shall maintain the Projects and Property in compliance with all applicable codes, laws, and
ordinances.
5.2 Affordable Housing. The DEVELOPER covenants and agrees that the two
(2) Project Units shall be sold only to Low-income families to constitute Affordable Housing,
as variously provided at 24 CFR 92.254, The City shall be entitled to injunctive relief to
enforce this provision.
5.3 Compliance With Environmental Laws. The DEVELOPER shall cause the
Project to be in compliance with, and not to cause or permit the housing project to be in
violation of, any environmental law, rule, regulation, ordinance, or statute. Although the
CITY will utilize its employees and agents for regular inspection and testing of the eligible
Property, the DEVELOPER agrees that, if the CITY has reasonable grounds to suspect any
such violation, the DEVELOPER shall be entitled to thirty (30) days' notice and opportunity
to cure such violation. If the suspected violation is not cured, the CITY shall have the right
to retain an independent consultant to inspect and test the eligible Property for such
violation. If a violation is discovered, the DEVELOPER shall pay for the reasonable cost of
the independent consultant.
Additionally, the DEVELOPER agrees:
A. That the CITY shall not be directly or indirectly involved with the
inspection, testing, removal or abatement of asbestos or other hazardous or toxic
Page 13 of 57
chemicals, materials, substances, or wastes and that all cost, expense and liability for such
work shall be and remain solely with the DEVELOPER;
B. Not to transport to or from the proposed project site(s), or use,
generate, manufacture, produce, store, release, discharge, or dispose of on, under, or
about the project site(s), or surrounding real estate, or transport to or from the project
site(s), or surrounding real estate, any hazardous or toxic chemicals, materials, substance,
or wastes or allow any person or entity to do so except in such amounts and under such
terms and conditions permitted by applicable laws, rules, regulations, ordinances, and
statutes;
C. To give prompt written notice to the CITY of the following:
1. Any proceeding or inquiry by any governmental authority with
respect to the presence of any hazardous or toxic chemicals, materials, substance, or
waste in or on the eligible Property or the surrounding real estate or the migration thereof
from or to other property;
2. All claims made or threatened by any third party against the
DEVELOPER or such properties relating to any loss or injury resulting from any hazardous
or toxic chemicals, materials, substance, or waste; and
3. The DEVELOPER'S discovery of any occurrence or condition
on any real property adjoining or in the vicinity of such properties that would cause such
properties or underlying or surrounding real estate or part thereof to be subject to any
restrictions on the ownership, occupancy, transferability, or use of the property under any
environmental law, rule, regulation, ordinance or statute.
D. To indemnify, defend, and hold the CITY harmless from any and all
claims, actions, causes of action, demands, judgments, damages, injuries, administrative
orders, consent agreements, orders, liabilities, penalties, costs, expenses (including
attorney's fees and expenses), and disputes of any kind whatsoever arising out of or
relating to the DEVELOPER or any other party's use or release of any hazardous or toxic
chemicals, materials, substance, or wastes on the eligible Property regardless of cause or
origin, including any and all liability arising out of or relating to any investigation, site
monitoring, containment, cleanup, removal, restoration, or other remedial work of any kind.
5.4 Compliance With Laws, The DEVELOPER shall promptly and faithfully
comply with, conform to and obey all present and future federal, state and local statutes,
regulations, rules, ordinances and other legal requirements applicable by reason of this
Agreement or otherwise to the Project. The DEVELOPER acknowledges that the use of
HOME Funds subjects the Project to extensive federal regulation and covenants and
agrees that it shall comply with, conform to and obey (and take such steps as are required
of the DEVELOPER to enable the CITY to comply with, conform to and obey) all federal
statutes, regulations, rules and policies applicable to the Program and the Project. The
CITY and DEVELOPER acknowledge that (i) pursuant to 24 CFR 92.354 a contract for the
rehabilitation of housing that includes fewer than 12 units assisted with HOME funds need
not contain a provision requiring the payment of the wages prevailing in the locality as
predetermined by the Secretary of Labor pursuant to the Davis -Bacon Act (40 U.S.C. 276a -
Page 14 of 57
276a-5), to all laborers and mechanics employed in the development of any part of the
housing, or the overtime provisions, as applicable, of the Contract Work Hours and Safety
Standards Act (40 U.S.C. 327-332), and (ii) pursuant to Cal. Labor Code 1720, the public
participation in the Project that would otherwise meet the criteria of a public work for which
State prevailing is required under Cal. Lab. Code 1720 et seq. is exempt where the public
funding is in the form of below-market interest rate loan for a project in which occupancy of
at least 40 percent of the units is restricted for at least 20 years, by deed or regulatory
agreement, to individuals or families earning no more that 80 percent of the area median
income. Nonetheless DEVELOPER shall be solely responsible for determining and
effectuating compliance. Notwithstanding anything to the contrary contained herein,
nothing in this Agreement shall be construed as imposing any independent prevailing wage
requirements that are different from those imposed by applicable federal or state law.
5.5 Existence. Qualification, and Authority. The DEVELOPER shall provide to
the CITY any evidence required or requested by the CITY to demonstrate the continuing
existence, qualification, and authority of the DEVELOPER to execute this Agreement and
to perform the acts necessary to carry out the Project.
5.6 Financial Statements and Audits. The DEVELOPER, as a recipient of federal
financial assistance, is required to comply with the provisions of the Single Audit Act of
1984 (31 U.S.C. Sections 7501 et seq.), as amended. Annually, within one hundred and
eighty (180) days following: 1) the end of fiscal year(s) in which the HOME Funds are
disbursed hereunder, and 2) the end of fiscal year(s) in which this contract shall terminate,
and otherwise upon the CITY'S, written request during the term of this Agreement,
DEVELOPER, at its sole cost and expense shall submit to the CITY:
A. Audited annual financial statements that are current, signed, and
prepared according to generally accepted accounting principles consistently applied
(except as otherwise disclosed therein); and
B. Audited Financial Statements covering the income and expenses, and
the financial transactions for the Project during the prior fiscal year.
5.7 Inspection and Audit of Books. Records and Documents. The DEVELOPER
shall be accountable to the CITY for all HOME Funds disbursed for this project pursuant to
this Agreement. Any duly authorized representative of the CITY, the State, or HUD shall,
at all reasonable times, have access to and the right to inspect, copy, make excerpts or
transcripts, audit, and examine all books of accounts, records, files and other papers or
property, and other documents of the DEVELOPER pertaining to the Project or all matters
covered in this Agreement and for up to six (6) years after the expiration or termination of
this Agreement.
A. The DEVELOPER will maintain books and records for the Project
using generally accepted accounting principles. The DEVELOPER agrees to maintain
books and records that accurately and fully show the date, amount, purpose and payee of
all expenditures financed with HOME Funds and to keep all invoices, receipts and other
documents related to expenditures financed with HOME Funds for not less than six (6)
years after the expiration or termination of the Agreement. Books and records must be
kept accurate and current. For purposes of this section, "books, records and documents"
Page 15 of 57
include, without limitation; plans, drawings, specifications, ledgers, journals, statements,
contracts/agreements, funding information, funding applications, purchase orders,
invoices, loan documents, computer printouts, correspondence, memoranda, and
electronically stored versions of the foregoing. This section shall survive the termination of
this Agreement.
B. The CITY may audit any conditions relating to this Agreement at the
CITY'S expense, unless such audit shows a significant discrepancy in information reported
by the DEVELOPER in which case the DEVELOPER shall bear the cost of such audit. The
DEVELOPER shall also comply with any applicable audit requirements of 24 CFR 92.506.
This section shall survive the termination of this Agreement.
C. The DEVELOPER will cooperate fully with the CITY, the State, and
HUD in connection with any interim or final audit relating to the Programs and the Project
that may be performed relative to the performance of this Agreement.
5.8 Inspection of Property. Any duly authorized representative of the CITY, the
State, or HUD shall, at all reasonable times, have access and the right to inspect the
Property until completion of the Project.
5.9 No Other Liens. The DEVELOPER shall not create or incur, or suffer to be
created or incurred, or to exist, any additional mortgage, pledge, encumbrance, lien,
charge, or other security interest of any kind on the eligible Property, other than those
related to rehabilitation or pre -development loans in relation to the Affordable Housing
Project consistent with the attached EXHIBIT "D" Project Budget, without the prior written
consent of the CITY.
5.10 Nondiscrimination. The DEVELOPER shall comply with and cause any and
all contractors and subcontractors to comply with any and all federal, state, and local laws
with regard to illegal discrimination, and the DEVELOPER shall not illegally discriminate
against any persons on basis of race, color, ancestry, national origin, religion, sex, age,
marital status, family status, source of income/rental assistance subsidy, physical or mental
disability, Acquired Immune Deficiency Syndrome (AIDS) or AIDS-related conditions
(ARC), sexual orientation, or any other arbitrary basis in its performance of this Agreement
and the completion of the Project.
5.11 Ownership. Except as required in pursuit hereof, the DEVELOPER shall not
sell, lease, transfer, assign or otherwise dispose of all or any material part of any interest it
might hold in the Property or the Project without the prior written consent of the CITY,
which consent shall not be unreasonably withheld or delayed.
5.12 Payment of Liabilities. The DEVELOPER shall pay and discharge in the
ordinary course of its business all material obligations and liabilities, the nonpayment of
which could have a material or adverse impact on its financial condition, business, or
assets or on the operation of the Project(s), except such obligations and liabilities that have
been disclosed to the CITY in writing and are being contested in good faith.
5.13 Report of Events of Default. The DEVELOPER shall promptly give written
notice to the CITY upon becoming aware of any Event of Default under this Agreement.
Page 16 of 57
ARTICLE 6. HOME PROGRAM FUNDS
Without waiver of limitation, the parties agree as follows, regarding HOME Funds:
6.1 Use of HOME Program Funds. The DEVELOPER warrants, covenants and
agrees that it shall request HOME Program Loan Funds only for reimbursement of HOME
eligible costs as identified in the attached Budget, limited to the amount needed,
aggregating not more than One Hundred Seventy Thousand Sixty Three Dollars and
00/100 ($170,063.00). The CITY'S obligations shall in no event exceed the HOME Funds
amount specified in this Agreement.
A. If any such Funds shall be determined to have been requested and/or
used by DEVELOPER for something other than for HOME eligible costs, and subject to the
notice and cure provisions of Section 10.2 hereunder, an equal amount from nonpublic
funds shall become immediately due and payable by DEVELOPER to the CITY; provided,
however that DEVELOPER shall, subject to its full cooperation with the CITY, be entitled to
participate in any opportunity to remedy, contest, or appeal such determination.
B. In the event HOME Funds are requested to reimburse for Eligible
Costs, which subsequently lose eligibility as Eligible Costs, DEVELOPER shall immediately
return such HOME Funds to the CITY.
C. The CITY will disburse HOME Funds, only to DEVELOPER through
proper invoicing, for HOME eligible costs of the Project as provided in this Article 6.
6.2 Conditions Precedent to Disbursement. The CITY shall not be obligated to
make or authorize any disbursements of HOME Funds or take any other action under this
Agreement unless all the following conditions are satisfied:
A. There exists no Event of Default as provided in Article 10, nor any act,
failure, ommission or condition that with the passage or time or the giving of notice or both
would constitute an Event of Default.
B. DEVELOPER has submitted evidence that the combined monies from
the Funding Sources and the HOME Funds are not less than Two Hundred Eighty
Thousand Sixty Three Dollars and 00/100 ($280,063.00) consistent with the Budget
attached hereto as EXHIBIT "C", the amount necessary to complete the Project.
C. The CITY has approved the requested payment of HOME eligible
Project costs.
D. DEVELOPER has acquired insurance coverage and delivered to the
CITY evidence of insurance as required in Article 9.
E. DEVELOPER is current with its compliance of all reporting
requirements set forth in this Agreement.
F. DEVELOPER has provided the CITY with a written request for HOME
Page 17 of 57
Funds (in CITY -approved Form), for payment of HOME eligible Project costs, and detailing
such Eligible Costs applicable to the request.
G. The CITY has received the Certification required by Section 6.4 of this
Agreement.
H. The CITY has received, and continued to have the right to disburse
HOME funds.
6.3 Request for and Disbursement of HOME Program Funds. DEVELOPER shall
request reimbursement of HOME Funds using the CITY's Request for Disbursement of
Funds Form, or a similar document. DEVELOPER shall only request a maximum of One
Hundred Seventy Thousand Sixty Three Dollars and 00/100 ($170,063.00), in HOME
Program assistance. All requests should provide in details such Eligible Costs applicable
to the request. All requests for HOME Funds disbursement shall be accompanied with the
Certification requiree by Section 6.4 of this Agreement.
6.4 DEVELOPER'S Certification. The DEVELOPER shall submit to the CITY a
written certification that, as of the date of the Request for Disbursement ("Certification"):
A. The representation and warranties contained in or incorporated by
reference in this Agreement continue to be true, complete and accurate;
B. The DEVELOPER has carried out all of its obligations and is in
compliance with all the obligations or covenants specified in this Agreement, to the extent
that such obligations or covenants are required to have been carried out or are applicable
at the time of the request for the Disbursement;
C. The DEVELOPER has not committed or suffered an act, event,
occurrence, or circumstance that constitutes an Event of Default or that with the passage of
time or giving of notice or both would constitute an Event of Default; and
D. The Loan disbursement requested will be used solely for
reimbursement of HOME eligible rehabilitation costs, and must be supported by the
itemized obligations that have been properly incurred and are properly chargeable in
connection with the Project.
ARTICLE 7. DEVELOPMENT AND REHABILITATION OF PROJECT
Without waiver of limitation, the parties agree as follows:
7.1 Pre -rehabilitation Meeting Regarding HOME Program Processes and
Procedures. CITY will schedule, and the DEVELOPER shall attend a meeting prior to
rehabilitation with the CITY'S Housing and Community Development Division Manager for
the purpose of outlining HOME program processes and procedures.
7.2 Commencement and Completion of Prosect. The DEVELOPER shall
commence and complete rehabilitation in accordance with the Project Description and
Schedule.
Page 18 of 57
7.3 Contracts and Subcontracts. Consistent with Article 5, all demolition,
hazardous waste abatement, rehabilitation work and professional services for the Project
shall be performed by persons or entities licensed or otherwise legally authorized to
perform the applicable work or service in the State of California and the City of Fresno.
The DEVELOPER shall provide the CITY with copies of all agreements with any and all
contractors or subcontractors for this Project. The DEVELOPER shall require that each
contractor and subcontractor agreement contain a provision whereby the party(ies) to the
agreement other than the DEVELOPER agree to (i) notify the CITY immediately of any
event of default by the DEVELOPER thereunder; (ii) notify the CITY immediately of the
filing of a mechanic's lien, (iii) notify the CITY immediately of termination or cancellation of
the agreement; and (iv) provide the CITY, upon the CITY'S request, an Estoppel Certificate
certifying that the agreement is in full force and effect and the DEVELOPER is not in
default thereunder. The DEVELOPER agrees to notify the CITY immediately of termination
or cancellation of any such agreement(s), notice of filing of a mechanic's lien, or breach or
default by other party(ies) thereto.
7.4 Damage to Property. To the extent consistent with the requirements of any
permitted encumbrance, or as otherwise approved by the CITY, and subject to Article 10 of
this Agreement, if any building or improvement constructed on the Property is damaged or
destroyed by an insurable cause, the DEVELOPER shall, at its cost and expense, diligently
undertake to repair or restore said buildings and improvements consistent with the original
scope of work of the Project Unit. Such work or repair shall commence within ninety (90)
days after the insurance proceeds are made available to the DEVELOPER and shall be
complete within one (1) year thereafter. All insurance proceeds collected for such damage
or destruction shall be applied to the cost of such repairs or restoration and, if such
insurance proceeds shall be insufficient for such purpose, the DEVELOPER shall make up
the deficiency.
7.5 Fees, Taxes and Other Levies, The DEVELOPER shall be responsible for
payment of all fees, assessments, taxes, charges and levies imposed by any public
authority or utility company with respect to the Property or the Project, and shall pay such
charges prior to delinquency. However, the DEVELOPER shall not be required to pay and
discharge any such charge so long as; (a) the legality thereof is being contested diligently
and in good faith and by appropriate proceedings, and (b) if requested by the CITY, the
DEVELOPER deposits with the CITY any funds or other forms of assurances that the
CITY, in good faith, may determine from time to time are appropriate to protect the CITY
from the consequences of the contest being unsuccessful.
7.6 Financing. The DEVELOPER shall promptly inform the CITY of any new or
additional financing or funding, and the DEVELOPER shall provide the CITY copies of all
agreements with any and all Funding Sources for this Project. The DEVELOPER shall
require each agreement with any and all Funding Sources to contain a provision whereby
the party(ies) to the agreement other than the DEVELOPER, agree to (i) notify the CITY
immediately of any event of default by the DEVELOPER thereunder; (ii) notify the CITY
immediately of termination or cancellation of the agreement; and (iii) provide the CITY,
upon CITY'S request, an Estoppel Certificate certifying that the agreement is in full force
and effect and the DEVELOPER is not in default thereunder. The DEVELOPER agrees to
notify the CITY immediately of termination or cancellation of any such agreement(s) or
Page 19 of 57
receipt of notice of default thereunder. The DEVELOPER shall comply with all obligations
of any such agreement(s) with any and all Funding Sources until the respective expiration
of such agreement(s). In the event DEVELOPER fails to comply with its obligations of this
section, the Loan shall become immediately due and payable as provided for in this
Agreement. This section shall survive expiration or termination of this Agreement.
7.7 Identification Signage. Before the start of rehabilitation, the DEVELOPER
shall place a poster or sign, with a minimum three feet by three feet in size, identifying the
City of Fresno, Planning and Development Department, Housing and Community
Development Division, as a Project participant. The sign shall also include the CITY'S
Logo, as well as the Equal Housing Opportunity logo, as mandated by HUD. Font size
shall be a minimum of 4 inches. The poster/sign shall be appropriately placed, and shall be
in place throughout the Project rehabilitation.
7.8 Inspections, The DEVELOPER shall permit, facilitate, and require its
contractors and consultants to permit and facilitate observation and inspection at the job
site by the CITY and other public authorities during reasonable business hours, for
determining compliance with this Agreement.
7.9 Insurance and Bonds. Upon CITY'S reasonable request, the DEVELOPER
shall submit for CITY approval bonds, policies, certificates and applicable endorsements for
all insurance and bonds required by this Agreement in accordance with Article 9.
7.10 Mechanic's Liens and Stop Notices. If any claim of lien is filed against the
Property or a stop notice affecting any financing, HOME Program Funds or Funding
Sources for the Project is served on the CITY or any other third party in connection with the
Project, the DEVELOPER shall, within twenty (20) days of such filing or service, either pay
and fully discharge the lien or stop notice, effect the release of such lien or stop notice by
delivering to the CITY a surety bond in sufficient form and amount, or provide the CITY with
other assurance satisfactory to the CITY that the claim of lien or stop notice will be paid or
discharged.
A. If the DEVELOPER fails to discharge, bond or otherwise satisfy the
CITY with respect to any lien, encumbrance, charge or claim referred to in this Section,
then, in addition to any other right or remedy, the CITY may, but shall not be obligated to,
discharge such lien, encumbrance, charge, or claim at the DEVELOPER expense.
Alternatively, the CITY may require the DEVELOPER to immediately deposit with the CITY
the amount necessary to satisfy such lien or claim and any costs, pending resolution
thereof. The CITY may use such deposit to satisfy any claim or lien that is adversely
determined against the DEVELOPER. The DEVELOPER hereby agrees to indemnify and
hold the CITY harmless from liability for such liens, encumbrances, charges or claims
together with all related costs and expenses.
7.11 Permits and Licenses. Upon CITY'S reasonable request, the DEVELOPER
shall submit, for CITY approval, all the necessary permits and licenses required for
Commencement of Rehabilitation. As the CITY may reasonably request, the
DEVELOPER, at its sole cost and expense, shall provide to the CITY copies of any and all
permit approvals and authorizations including plot plan, plat, zoning variances, sewer,
building, and other permits required by governmental authorities other than the CITY in
Page 20 of 57
pursuit of the Affordable Housing Project, and for its stated purposes in accordance with all
applicable building, environmental, ecological, landmark, subdivision, zoning codes, laws,
and regulations. The DEVELOPER is responsible, at its sole cost and expense, to
determine the location of any utilities on the Property and to negotiate with the utility
companies for and to relocate the utilities, if any, as necessary to complete the Project.
7.12 Scope of Work. Before Commencement of Rehabilitation, the DEVELOPER
shall submit to the CITY, for its review and approval, the final Scope of Work for the
Projects. The DEVELOPER will rehabilitate the homes in full conformance with the Scope
of Work and modifications thereto approved by the CITY. The DEVELOPER shall obtain
the CITY'S prior written approval for any modifications to the Scope of Work.
7.13 Project Responsibilities. The DEVELOPER shall be solely responsible for all
aspects of the DEVELOPER'S conduct in connection with the Project, including but not
limited to, the applicability of and compliance with all local, state and federal laws including,
without limitation, as to prevailing wage and public bidding requirements (the CITY'S
annual resolution setting out per diem wage rates is available from the CITY'S
Rehabilitation Management Division), the quality and suitability of the work completed, the
supervision of all contracted work, qualifications and financial conditions of and
performance of all contractors, subcontractors, consultants and suppliers. Any review or
inspection undertaken by the CITY with reference to the Project is solely for the purpose of
determining whether the DEVELOPER is properly discharging its obligation to the CITY,
and shall not be relied upon by the DEVELOPER or by any third parties as a warranty or
representation by the CITY as to the quality of the work completed for the Project. This
Project is a public work subject to prevailing wage requirements except as provided in
Section 5.4 hereof.
7.14 Quality of Work. The DEVELOPER shall ensure that rehabilitation of the
proposed Project employs building materials of a quality suitable for the requirements of
the Project. The DEVELOPER shall cause completion of rehabilitation of the proposed
Project on the Property in full conformance with applicable local, state and federal laws,
statutes, regulations, and building and housing codes.
7.15 Relocation. If and to the extent that rehabilitation of the proposed Project
results in the permanent or temporary displacement of residential tenants, homeowners or
businesses, the DEVELOPER shall comply with all applicable local, state and federal
statutes and regulations with respect to relocation planning, advisory assistance and
payment of monetary benefits. The DEVELOPER shall be solely responsible for payment
of any relocation benefits to any displaced persons and any other obligations associated
with complying with said relocation laws.
7.16 Reporting Requirements. The DEVELOPER shall submit to the CITY the
following Project reports:
A. From the date of the Commence of the Project, until issuance of the
final Certificate of Completion, evidencing the completion of rehabilitation of the last Project
Unit, the DEVELOPER shall submit a Quarterly Report, in a form approved by the CITY,
which will include, at a minimum, the following information: progress of the Project and
affirmative marketing efforts (as applicable). The Quarterly Reports are due fifteen (15)
Page 21 of 57
days after the end of each March 315`, June 30`h, September 30`h, and December 315`
during said period.
B. Annually, beginning on the first day of the month following the CITY'S
issuance of the final Certificate of Completion, evidencing the rehabilitation of the last
Project Unit, and continuing until the termination of the Agreement, the DEVELOPER shall
submit an Annual Report to the CITY, in a form approved by the CITY. The Annual Report
shall include, at a minimum, the following information: the date the occupancy commenced,
certification from an officer of the DEVELOPER that the Project is in compliance with the
Affordable Housing Requirements, and such other information the CITY may be required
by law to obtain. The DEVELOPER shall provide any additional information reasonably
requested by the CITY.
C. Annually, beginning on the first day of the month following the CITY'S
issuance of the final Certificate of Completion, evidencing the rehabilitation of the last
Project Unit, and continuing until the expiration of the Agreement, DEVELOPER shall
submit proof of insurance as may be required in Article 10.
7.17 Scheduling and Extension of Time: Unavoidable Delay in Performance. It
shall be the responsibility of the DEVELOPER to coordinate and schedule the work to be
performed so that the Commencement of the Project and issuance of the Certificate of
Completion(s) will take place in accordance with the provisions of the Agreement. The
CITY, through its Housing and Community Development Division Manager, may extend
such time in writing at its sole and absolute discretion, and upon written request of the
DEVELOPER, as follows:
A. The time for performance of provisions of the Agreement by either
party shall be extended for a period equal to the period of any delay directly affecting the
Project or this Agreement which is caused by: war, insurrection, strike or other labor
disputes, lock -outs, riots, floods, earthquakes, fires, casualties, acts of God, acts of a public
enemy, epidemics, quarantine restrictions, freight embargoes, lack of transportation, suits
filed by third parties concerning or arising out of this Agreement, or unseasonable weather
conditions. An extension of time for any of the above specified causes will be granted only
if written notice by the party claiming such extension is sent to the other party within ten
(10) calendar days from the date the affected party learns of the commencement of the
cause and the resulting delay and such extension of time is accepted by the other party in
writing. In any event, the Project must be completed no later than one hundred eighty
(180) calendar days after the scheduled completion date specified in this Agreement,
notwithstanding any delay caused by that included in this section.
B. Any and all extensions hereunder shall be by mutual written
agreement of the CITY'S Housing and Community Development Division Manager and the
DEVELOPER and shall not cumulatively exceed one hundred eighty (180) days.
7.18 Certificate of Completion. Upon completion of the rehabilitation of each
Project Unit, the DEVELOPER shall certify, in writing, within thirty (30) days, to the CITY
that rehabilitation of the Project Unit has been completed in accordance with the scope of
work approved by the CITY. Upon completion of each Project Unit, the DEVELOPER shall
also submit to the CITY a cost -certifying final budget where the DEVELOPER shall identify
Page 22 of 57
the actual costs of rehabilitation of each Project Unit. This final cost -certification shall
identify costs in line -item format, consistent with the Project Budget. Upon a determination
by the CITY that the DEVELOPER is in compliance with all of the DEVELOPER'S
rehabilitation obligations, as specified in this Agreement, for that Project Unit, the CITY
shall furnish, within thirty (30) calendar days of a written request by the DEVELOPER, a
recordable Certificate of Completion for the Project(s) in the form attached hereto as
EXHIBIT 'E". The CITY will not unreasonably withhold or delay furnishing the Certificate of
Completion. If the CITY fails to provide the Certificate of Completion within the specified
time, it shall provide the DEVELOPER with a written statement indicating in what respects
the DEVELOPER has failed to complete the Project in conformance with this Agreement or
has otherwise failed to comply with the terms of this Agreement, and what measures the
DEVELOPER will need to take or what standards it will need to meet in order to obtain the
Certificate of Completion. Upon the DEVELOPER taking the specified measures and
meeting the specified standards, the DEVELOPER will certify to the CITY in writing of such
compliance and the CITY shall deliver the recordable Certificate of Completion to the
DEVELOPER in accordance with the provisions of this section.
F-\.ANIS] ] :]■7:7�19��i1ti77_� 7•�i[�INkK
8.1 Operation of the Project. The DEVELOPER shall operate and/or manage the
Project in full conformity with the terms of this Agreement.
8.2 Occupancy Requirements. Two (2) Project Unit(s) shall be marketed and
sold as principal residence for single-family owner -occupancy by low-income households.
The DEVELOPER shall comply with the income targeting and Affordable Housing
requirements of 24 CFR 92.217 and 92.254. The CITY shall approve in advance all
homebuyers. No homebuyer shall take occupancy of any home prior to the close of
escrow vesting title in said homebuyer.
8.3 Homebuyer Selection. The DEVELOPER is responsible for selecting eligible
homebuyer(s) for property purchase(s) consistent with this Agreement and HOME
regulations. The DEVELOPER will sell the assisted property to the first eligible homebuyer
who offers to purchase the property at the Maximum Allowable Sales Price as defined
below. If the first offer is found to be ineligible, then the DEVELOPER will sell the property
to the second homebuyer who offers to purchase the property at the Maximum Allowable
Sales Price, and so on. If the DEVELOPER does not receive any offers at the Maximum
Allowable Sales Price, the DEVELOPER may sell the assisted property to the first eligible
homebuyer who offers to purchase the property at the reduced asking price, as identified
below. The CITY shall verify HOME eligibility, in advance, for all homebuyers as pre-
selected by the DEVELOPER. Homebuyer financing shall be based upon buyer's ability to
pay, consistent with this Agreement. The CITY will require homebuyers to provide three
percent (3%) cash contribution towards their home purchase.
8.4 Property Home Sale Price. The maximum allowable sales price (hereinafter
"Maximum Allowable Sales Price") for a property is determined by a fair market appraisal.
The property is subject to 24 CFR 92.254 affordability requirements, including the
requirement that the sale price of each home shall not exceed ninety five percent (95%) of
the median purchase price for the area. Each assisted property shall be initially listed for
sale at the Maximum Allowable Sales Price for a period of fifteen (15) days (hereinafter the
Page 23 of 57
"Initial Listing Period"). In the event the DEVELOPER has not received an offer to
purchase the property at the Maximum Allowable Sales Price during the Initial Listing
Period, commencing on the 16th day and continuing through the thirtieth (301h) day
(hereinafter the "Secondary Listing Period"), the DEVELOPER may accept a purchase offer
below the Maximum Allowable Sales Price provided that the offer amount is no more than
$5,000 below the Maximum Allowable Sales Price. In the event the DEVELOPER does not
receive an acceptable offer to purchase the property during the Secondary Listing Period,
the City will consider approving a further reduction of the Maximum Allowable Sales Price if
requested by the DEVELOPER and approved by the CITY in writing. The acceptance of
an offer to purchase the property, in any and all such events, shall be conditioned upon the
purchaser's agreement to assume the Note.
8.5 Affirmative Fair Housing Marketing Plan. Before marketing any Project Unit
and at least sixty (60) calendar days prior to the Completion of the first Project Unit, the
DEVELOPER shall submit to the CITY, for review and approval, a plan for marketing the
sale of the Unit(s) ("Marketing Plan"). The Marketing Plan shall address in detail how the
DEVELOPER or its designated management entity plans to market the availability of Units
to prospective low-income purchasers and how the DEVELOPER plans to certify the
eligibility of potential buyers. The Marketing Plan shall contain detailed descriptions of
policies and procedures with respect to buyer selection(s). Topics to be covered in these
procedures shall include at a minimum the following:
• Interviewing procedures for prospective buyers;
• Non -Discrimination Provisions;
• Buyer references;
• Credit reports and checks;
• Deposit amounts, purpose, use and refund policy;
• Employment/income verification;
• Occupancy restrictions;
• Income limits;
• Homebuyer education requirements;
• Equal Housing Opportunity Statement; and
• Restrictions on use of the premises and Program Income.
The Marketing Plan shall contain copies of all standardized forms associated
with the above listed topics. The DEVELOPER shall abide by the terms of this Marketing
Plan, approved by the CITY, in marketing, managing and selling the Housing.
8.6 Property Management. With respect to the Project, DEVELOPER shall
comply with the following:
A. Management Responsibilities. The DEVELOPER is specifically
responsible for all management functions with respect to the Project including, without
limitation, rehabilitation management, affirmative marketing, property disposition and initial
certification of household size and income. The DEVELOPER during its time on title shall
be responsible for Project maintenance, landscaping, routine and extraordinary repairs,
replacement of capital items and security. The CITY shall have no responsibility for such
management of the Project.
Page 24 of 57
8.7 Maintenance and Security. The DEVELOPER shall (i) at its own expense
maintain the homes in good condition, in good repair and in decent, safe, sanitary,
habitable and tenantable living conditions for the benefit of the purchasers, (ii) not commit
or permit any waste on or to the homes, and shall prevent and/or rectify any physical
deterioration of the homes; and (iii) maintain the homes in conformance with all applicable
federal, state and local laws, ordinances, codes and regulations and this Agreement, until
such are sold to Low -Income buyers.
8.8 Nondiscrimination. All of the Units shall be available for initial purchase to
members of the general public who are income eligible. The DEVELOPER shall not
illegally discriminate or segregate in the development, rehabilitation, use, enjoyment,
occupancy or conveyance of any part of the Affordable Housing Project or Property on the
basis of race, color, ancestry, national origin, religion, sex, age, marital status, family
status, source of income/rental assistance subsidy, physical or mental disability, Acquired
Immune Deficiency Syndrome (AIDS) or AIDS-related conditions (ARC), sexual orientation,
or any other arbitrary basis. The DEVELOPER shall otherwise comply with all applicable
local, state and federal laws concerning nondiscrimination in housing. Neither the
DEVELOPER nor any person claiming under or through the DEVELOPER, shall establish
or permit any such practice or practices of illegal discrimination or segregation with
reference to the selection, location, number, use or occupancy of tenants or vendees of
any Unit or in connection with employment of persons for the rehabilitation of any Unit. All
deeds or contracts made or entered into by the DEVELOPER as to the Units or the housing
project or portion thereof, shall contain covenants concerning nondiscrimination consistent
with this section. The DEVELOPER shall include a statement in all advertisements, notices
and signs for availability of Units to the effect that the DEVELOPER is an Equal Housing
Opportunity Provider.
A. Nothing in this section is intended to require the DEVELOPER to
change the character, design, use or operation of the Project; or to require the
DEVELOPER to obtain licenses or permits other than those required for the Project.
8.9 Affordable Housing. The purpose of this Agreement is to use HOME Loan
Funds to ensure the affordability of two (2) Project Units to be sold to Low -Income
households. The DEVELOPER, and those taking ownership of the Project Property under
or through it/them, covenant and agree that the Project shall constitute Affordable Housing
by ensuring that the homes are sold only to Low -Income households.
A. If a Project Unit initially built and sold to a lower-income household is
subsequently resold, otherwise transferred and/or is no longer the principal residence of
the individual(s) who initially purchased the property as Affordable Housing during the
Affordability Period, and without waiver or limitation, the entire HOME -Funded Loan
allocated to Unit shall be repaid to/recaptured by the CITY'S HOME Program Trust Fund
and thereupon the balance of the Affordability Covenant/Period shall be released.
B. The DEVELOPER shall require that each initial homebuyer assume
the Loan. Said Trust Deed Note(s) as assumed shall be security for the provision of HOME
Funding for the Project by the CITY. In the event of a failure to comply with the
Affordability Restrictions, in addition to any and all other remedies available to it, the CITY
Page 25 of 57
shall be entitled to enjoin sale of the Project Units, damages not being an adequate remedy
at law for such breach.
ARTICLE 9. INDEMNIFICATION AND INSURANCE.
Without waiver of limitation, the parties agree as follows regarding the DEVELOPER'S
Indemnification and Insurance Obligations:
9.1 Indemnification. The DEVELOPER shall indemnify, hold harmless and
defend the CITY and each of its officers, officials, employees, agents and volunteers from
any and all loss, liability, fines, penalties, forfeitures, costs and damages (whether in
contract, tort or strict liability, including but not limited to personal injury, death at any time
and property damage) incurred by the CITY, the DEVELOPER or any other person, and
from any and all claims, demands and actions in law or equity (including attorney's fees
and litigation expenses), arising or alleged to have arisen directly or indirectly out of
performance of this Agreement. The DEVELOPER'S obligations under the preceding
sentence shall apply regardless of whether CITY or any of its officers, officials, employees,
agents or authorized volunteers are negligent, but shall not apply to any loss, liability, fines,
penalties, forfeitures, costs or damages caused solely by the gross negligence, or caused
by the willful misconduct, of CITY or any of its officers, officials, employees, agents or
authorized volunteers.
A. If the DEVELOPER should contract all or any portion of the work to be
performed under this Agreement, the DEVELOPER shall require each contractor and
subcontractor to indemnify, hold harmless and defend the CITY and each of its officers,
officials, employees, agents and volunteers in accordance with the terms of the preceding
paragraph.
B. This section shall survive termination or expiration of this Agreement.
9.2 Insurance. Throughout the life of this Agreement, the DEVELOPER shall
itself and/or through its consultant(s), assignee(s), nominee(s), contractors and
subcontractors pay for and maintain in full force and effect all policy(ies) of insurance
required hereunder with (an) insurance company(ies) either (1) admitted by the California
Insurance Commissioner to do business in the State of California and rated not less than
"A -VII" in Best's Insurance Rating Guide, or (2) authorized by the CITY'S Risk Manager.
The following policies of insurance are required:
A. Until issuance of Certificate(s) of Completion, BUILDERS RISK
(Course of Rehabilitation) insurance in an amount equal to the completed value of the
project with no coinsurance penalty provisions.
B. Following issuance of Certificate(s) of Completion: COMMERCIAL
PROPERTY insurance, which shall be at least as broad as the most current version of
Insurance Service Office (ISO) Commercial Property Form CP 10 30 (Cause of Loss —
Special Form), with limits of insurance in an amount equal to the full (100%) replacement
cost (without deduction for depreciation) of the Improvements with no coinsurance penalty
provisions.
Page 26 of 57
1. The above described policy(ies) of insurance shall be endorsed to
provide that the coverage shall not be cancelled, non -renewed, reduced in coverage or in
limits except after thirty (30) calendar day written notice has been given to CITY of policy
cancellation, change or reduction of coverage. Upon issuance by the insurer, broker, or
agent of a notice of cancellation, non -renewal, change or reduction in coverage, the
DEVELOPER or its contractors/subcontractors, as the case may be, shall furnish CITY with
a new certificate and applicable endorsements for such policy(ies). In the event the policy
is due to expire during the term of this Agreement, DEVELOPER shall provide a new
certificate, and applicable endorsements, a new certificate evidencing renewal of such
policy shall be provided not less than fifteen (15) days prior to the expiration date of the
expiring policy. Upon issuance by the insurer, broker, or agent of a notice of cancellation,
change or reduction in coverage, the DEVELOPER or its contractors/subcontractors, as the
case may be, shall file with the CITY a certified copy of the new or renewal policy and
certificates for such policy.
2. The Builders Risk (Course of Construction) and Property Insurance
policies shall name the CITY as a loss payee. The insurance required herein shall contain
no special limitations on the scope of protection afforded to the CITY.
3. If at any time during the life of this Agreement or any extension, the
DEVELOPER fails to maintain the required insurance in full force and effect, all work under
this Agreement shall be discontinued immediately, until notice is received by the CITY that
the required insurance has been restored to full force and effect and that the premiums
therefore have been paid for a period satisfactory to the CITY. Any failure to maintain the
required insurance, subject to notice and cure requirements herein, shall be sufficient
cause for the CITY to terminate this Agreement.
9.3 Bonds. The DEVELOPER shall obtain, pay for and deliver or cause to be
obtained, paid for and delivered good and sufficient surety bonds from a corporate surety,
admitted by the California Insurance Commissioner to do business in the State of California
and Treasury -listed, in a form satisfactory to the CITY and naming the CITY as Co -Obligee.
A. The "Faithful Performance Bond" shall be at least equal to 100% of
DEVELOPER'S estimated rehabilitation costs to guarantee faithful performance of the
Project, within the time prescribed, in a manner satisfactory to the CITY, and that all
materials and workmanship will be free from original or developed defects.
B. The "Material and Labor Bond" shall be at least equal to 100% of
DEVELOPER'S estimated rehabilitation costs to satisfy claims of material supplies and of
mechanics and laborers employed for this Project. The bond shall be maintained by
DEVELOPER in full force and effect until the Project is completed, and until all claims for
materials and labor are paid, released, or time barred, and shall otherwise comply with any
applicable provisions of Title 15, Part 4, Division 3 of the California Civil Code.
C. In lieu of the bonds required above, CITY in its sole discretion may
accept from DEVELOPER an Irrevocable Standby Letter of Credit issued with the CITY
named as the sole beneficiary. The Irrevocable Standby Letter of Credit is to be issued by
a bank, and in a form, acceptable to CITY. This Irrevocable Standby Letter of Credit shall
Page 27 of 57
be maintained by DEVELOPER in full force and effect until the Notice of Completion is
recorded and shall be subject to and governed by the laws of the State of California.
ARTICLE 10. DEFAULT AND REMEDIES
10.1 Events of Default. The parties agree that each of the following shall
constitute an "Event of Default" for purposes of this Agreement:
A. The DEVELOPER'S use of HOME Funds for costs other than Eligible
Costs or for uses not permitted by the terms of this Agreement;
B. The DEVELOPER'S failure to obtain and maintain the insurance
coverage required under this Agreement;
C. Except as otherwise provided in this Agreement, the failure of the
DEVELOPER to punctually and properly perform any other covenant or agreement
contained in this Agreement including without limitation the following: (1) the
DEVELOPER'S substantial deviation in the Project work specified in the Project
Description as identified in this Agreement, without the CITY'S prior written consent; (2) the
DEVELOPER'S use of defective or unauthorized materials or defective workmanship in
pursuit of the Project; (3) the DEVELOPER'S failure to commence or complete the Project,
as specified in this Agreement, unless delay is permitted under this Agreement; (4) the
cessation of the Project for a period of more than fifteen (15) consecutive days (other than
as provided in this Agreement) prior to submitting to the CITY certification that the Project
is complete; (5) any material adverse change in the condition of the DEVELOPER or the
Project that gives the CITY reasonable cause to believe that the Project cannot be
completed by the scheduled completion date according to the terms of this Agreement; (6)
the DEVELOPER'S failure to remedy any deficiencies in record keeping or failure to
provide records to the CITY upon the CITY'S request; (7) the DEVELOPER'S failure to
substantially comply with any federal, state or local laws or applicable CITY restrictions
governing the Project, including but not limited to provisions of this Agreement pertaining to
equal employment opportunity, nondiscrimination and lead-based paint;
D. Any representation, warranty, or certificate given or furnished by or on
behalf of the DEVELOPER shall prove to be materially false as of the date of which the
representation, warranty, or certification was given, or that the DEVELOPER concealed or
failed to disclose a material fact to the CITY, provided, however, that if any representation,
warranty, or certification that proves to be materially false is due merely to the
DEVELOPER'S inadvertence, the DEVELOPER shall have a thirty (30) day opportunity
after written notice thereof to cause such representation, warranty, or certification to be true
and complete in every respect;
E. The DEVELOPER shall file, or have filed against it, a petition of
bankruptcy, insolvency, or similar law, state or federal, or shall file any petition or answer
seeking, consenting to, or acquiescing in any reorganization, arrangement, composition,
readjustment, liquidation, dissolution, or similar relief, and such petition shall not have been
vacated within fourteen (14) days; or shall be adjudicated bankrupt or insolvent, under any
present or future statute, law, regulation, under state or federal law, and such judgment or
decree is not vacated or set aside within fourteen (14) days;
Page 28 of 57
F. The DEVELOPER'S failure, inability or admission in writing of its
inability to pay its debts as they become due or the DEVELOPER assignment for the
benefit of creditors;
G. A receiver, trustee, or liquidator shall be appointed for the
DEVELOPER or any substantial part of the DEVELOPER'S assets or properties, and not
be removed within ten (10) days;
H. The failure of the DEVELOPER to cause completion of the Project
pursuant to the Schedule in Exhibit B;
I. The DEVELOPER'S breach of any other material condition, covenant,
warranty, promise or representation contained in this Agreement not otherwise identified
within this Section: and
J. Any substantial or continuous breach by the DEVELOPER of any
material obligation owed by the DEVELOPER imposed by any other agreement with
respect to the financing, development, rehabilitation or operation of the Project, whether or
not the CITY is a party to such agreement.
10.2 Notice of Default and Opportunity to Cure. The CITY shall give written notice
to the DEVELOPER of any Event of Default by specifying (1) the nature of the event or
deficiency giving rise to the default, (2) the action required to cure the deficiency, if any
action to cure is possible, and (3) a date, which shall not be less than the lesser of any time
period provided in this Agreement, any time period provided for in the notice, or thirty (30)
calendar days from the date of the notice, by which such deficiency must be cured,
provided that if the specified deficiency or default cannot reasonably be cured within the
specified time, with the CITY'S written consent, the DEVELOPER shall have an additional
reasonable period to cure so long as it commences cure within the specified time and
thereafter diligently pursues the cure in good faith.
10.3 Remedies Upon an Event of Default. Upon the happening of an Event of
Default by the DEVELOPER and a failure to cure said Event of Default within the time
specified, the CITY may also at its option and without notice institute any action, suit, or
other proceeding in law, in equity or otherwise, which it shall deem necessary or proper for
the protection of its interests and may without limitation proceed with any or all of the
following remedies in any order or combination that the CITY may choose in its sole
discretion:
A. Terminate this Agreement immediately upon written notice to the
DEVELOPER;
B. Bring an action in equitable relief (1) seeking specific performance by
the DEVELOPER of the terms and conditions of this Agreement, and/or (2) enjoining,
abating or preventing any violation of said terms and conditions, and/or (3) seeking
declaratory relief; and
Pursue any other remedy allowed by law or in equity or under this Agreement.
Page 29 of 57
ARTICLE 11. GENERAL PROVISIONS.
Without waiver of limitation, the parties agree that the following general provisions shall
apply in the performance hereof:
11.1 Amendments. No modification or amendment of any provision of this
Agreement shall be effective unless made in writing and signed by the parties hereto.
11.2 Attorney's Fees. If either party is required to commence any proceeding or
legal action to enforce or interpret any term, covenant or condition of this Agreement, the
prevailing party will be entitled to recover from the other party its reasonable attorney's fees
and legal expenses.
11.3 Binding on All Successors and Assigns. Unless otherwise expressly provided
in this Agreement, all the terms and provisions of this Agreement shall be binding on and
inure to the benefit of the parties hereto, and their respective nominees, heirs, successors,
assigns, and legal representatives.
11.4 Counterparts. This Agreement may be executed in counterparts, each of
which when executed and delivered will be deemed an original, and all of which together
will constitute one instrument. The execution of this Agreement by any party hereto will not
become effective until counterparts hereof have been executed by all parties hereto.
11.5 Disclaimer of Relationship. Nothing contained in this Agreement, nor any act
of the CITY or of the DEVELOPER, or of any other person, shall in and by itself be deemed
or construed by any person to create any relationship of third party beneficiary, or of
principal and agent, of limited or general partnership, or of joint venture.
11.6 Discretionary Governmental Actions. Certain planning, land use, zoning and
other permits and public actions required in connection with the Project including, without
limitation, the approval of this Agreement, the environmental review and analysis under
NEPA, CEQA or any other statute, and other transactions contemplated by this Agreement
are discretionary government actions. Nothing in this Agreement obligates the CITY or any
other governmental entity to grant final approval of any matter described herein. Such
actions are legislative, quasi-judicial, or otherwise discretionary in nature. The CITY cannot
take action with respect to such matters before completing the environmental assessment
of the Project under NEPA, CEQA and any other applicable statutes. The CITY cannot and
does not commit in advance that it will give final approval to any matter. The CITY shall not
be liable, in contract, law or equity, to the DEVELOPER or any of its executors,
administrators, transferees, successors -in -interest or assigns for any failure of any
governmental entity to grant approval on any matter subject to discretionary approval.
11.7 Effective Date, This Agreement shall be effective upon the date first above
written, upon the parties' complete execution following CITY Council approval.
11.8 Entire Agreement. This Agreement represents the entire and integrated
agreement of the parties with respect to the subject matter hereof. This Agreement
supersedes all prior negotiations, representations or agreements, either written or oral.
Page 30 of 57
11.9 Exhibits. Each exhibit and attachment referenced in this Agreement is, by the
reference, incorporated into and made a part of this Agreement.
11.10 Expenses Incurred Upon Event of Default. The DEVELOPER shall reimburse
the CITY for all reasonable expenses and costs of collection and enforcement, including
reasonable attorney's fees, incurred by the CITY as a result of one or more Events of
Default by the DEVELOPER under this Agreement.
11.11 Governing Law and Venue. Except to the extent preempted by applicable
federal law, the laws of the State of California shall govern all aspects of this Agreement,
including execution, interpretation, performance, and enforcement. Venue for filing any
action to enforce or interpret this Agreement will be Fresno, California.
11.12 Headings. The headings of the articles, sections, and paragraphs used in
this Agreement are for convenience only and shall not be read or construed to affect the
meaning or rehabilitation of any provision.
11.13 Interpretation. This Agreement in its final form is the result of the combined
efforts of the parties. Any ambiguity will not be construed in favor or against any party, but
rather by construing the terms in accordance with their generally accepted meaning.
11.14 No Assignment or Succession. Except as may be otherwise expressly
provided by this Agreement, neither this Agreement, nor any interest of the DEVELOPER
in, under, or to this Agreement, or the Project, may be assigned or transferred by the
DEVELOPER without the prior written consent of the CITY, which consent shall not be
unreasonably withheld or delayed. Any assignment without consent is null and void.
11.15 No Third -Party Beneficiary. No contractor, subcontractor, mechanic,
materialman, laborer, vendor, or other person hired or retained by the DEVELOPER shall
be, nor shall any of them be deemed to be, third -party beneficiaries of this Agreement, but
each such person shall be deemed to have agreed (a) that they shall look to the
DEVELOPER as their sole source of recovery if not paid, and (b) except as otherwise
agreed to by the CITY and any such person in writing, they may not enter any claim or
bring any such action against the CITY under any circumstances. Except as provided by
law, or as otherwise agreed to in writing between the CITY and such person, each such
person shall be deemed to have waived in writing all right to seek redress from the CITY
under any circumstances whatsoever.
11.16 No Waiver. Neither failure nor delay on the part of the CITY in exercising any
right under this Agreement shall operate as a waiver of such right, nor shall any single or
partial exercise of any such right preclude any further exercise thereof or the exercise of
any other right. No waiver of any provision of this Agreement or consent to any departure
by the DEVELOPER therefrom shall be effective unless the same shall be in writing, signed
on behalf of the CITY by a duly authorized officer thereof, and the same shall be effective
only in the specific instance for which it is given. No notice to or demand on the
DEVELOPER in any case shall entitle the DEVELOPER to any other or further notices or
demands in similar or other circumstances, or constitute a waiver of any of the CITY'S right
to take other or further action in any circumstances without notice or demand.
Page 31 of 57
11.17 Nonreliance. The DEVELOPER hereby acknowledges having obtained such
independent legal or other advice as it has deemed necessary and declares that in no
manner has it relied on the CITY, it agents, employees or attorneys in entering into this
Agreement.
11.18 Notice. Any notice to be given to either party under the terms of this
Agreement shall be given by certified United States mail, postage prepaid, return receipt
requested, at the addresses specified below, or at such other addresses as may be
specified in writing by the parties.
If to the CITY: City of Fresno
Housing and Community Development Division
2600 Fresno Street, Room 3070
Fresno, CA 93721-3605
If to DEVELOPER: Housing Authority of City of Fresno
Attn: Preston Prince
1331 Fulton Mall
Fresno, CA 93721
11.19 Precedence of Documents. In the event of any conflict between the body of
this Agreement and any exhibit or attachment hereto, the terms and conditions of the body
of this Agreement will control.
11.20 Recording of Documents. The DEVELOPER agrees to cooperate with the
CITY and execute any documents required, promptly upon the CITY'S request, the Deed(s)
of Trust, and any other documents/instruments that the CITY requires to be recorded, in
the Official Records of Fresno County, California, consistent with this Agreement.
11.21 Remedies Cumulative. All powers and remedies given by this Agreement
shall be cumulative and in addition to those otherwise provided by law.
11.22 Severabilitv. The invalidity, illegality, or un -enforceability of any one or more
of the provisions of this Agreement shall not affect the validity, legality, or enforceability of
the remaining provisions hereof or thereof.
///
Page 32 of 57
IN WITNESS WHEREOF, the parties have executed this Agreement in Fresno,
California, the day and year first above written.
CITY OF FRESNO, a Municipal Corporation
By: Ata,
Mark Scott, City Manager
(Attach notary certificate of acknowledgment)
Date: 47—//
ATTEST: APPROVED AS TO FORM:
REBECCA E. KLISCH JAMES SANCHEZ
City Clerk City Attorney
Date: 47 %-`i
DEVELOPER
Housing Authority of the City of Fresno
By: —
Preston Prince, Executive Director
(Attach notary certificate of acknowledgment)
Date: 912 3A 1
Attachments:
By:
Deputy City Attorney
Date: - I-01- I
EXHIBIT A:
PROPERTY DESCRIPTION
EXHIBIT B:
PROJECT DESCRIPTION AND SCHEDULE
EXHIBIT C:
EXEMPLAR DECLARATION OF RESTRICTIONS
EXHIBIT D:
BUDGET
EXHIBIT E:
EXEMPLAR CERTIFICATE OF COMPLETION
EXHIBIT F1:
EXEMPLAR NOTE AND TEMPLATE RIDER TO DEED(S) OF TRUST
EXHIBIT F2:
EXEMPLAR NOTE AND TEMPLATE RIDER TO DEED(S) OF TRUST
EXHIBIT G:
GUIDE TO REHABILITATION STANDARDS
Page 33 of 157
ALL PURPOSE ACKNOWLEDGMENT
State of California
County of Fresno
On September 23, 2011 before me, Nancy A. Andersen Notary Public,
personally appeared Preston Prince who
proved to me on the basis of satisfactory evidence to be the person(s) whose
name(s) is/are subscribed to the within instrument and acknowledged to me that
he/she/they executed the same in his/her/their authorized capacity(ies), and
that by his/her/their signature(s) on the instrument the person(s), or the entity
upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California
that the foregoing paragraph is true and correct.
WITNESS my hand and official sea[.
NANCY A. ANDERSEN
• COMM. #!$91151
s Notary Publi�Caliiornia
W FRESN jC
MH Comm. E'. MAY 27, W,
( -1. -- (Seal)
No ignature
EXHIBIT A
PROPERTY DESCRIPTION
375 N. PARK (459-143-03T)
BEGINNING AT A POINT IN THE WEST LINE OF PARK AVENUE, DISTANT THEREON
98 FEET SOUTH FROM THE NORTH LINE OF LOT 1 OF THE SUBDIVISION OF LOTS
12 AND 13 OF PARK ADDITION, AND RUNNING THENCE WEST PARALLEL WITH
SAID NORTH LINE OF LOT 1, A DISTANCE OF 90.5 FEET, MORE OR LESS, TO A
POINT 90.5 FEET EAST FROM THE WEST LINE OF LOT 2 OF SAID SUBDIVISION;
THENCE SOUTH PARALLEL WITH THE WEST LINE OF LOTS 2 AND 3 OF SAID
SUBDIVISION TO THE SOUTH LINE OF LOT 3; THENCE EAST ALONG SAID SOUTH
LINE OF LOT 3 TO THE WEST LINE OF PARK AVENUE; THENCE NORTH ALONG THE
WEST LINE OF PARK AVENUE TO THE POINT OF BEGINNING.
459-143-03T
380 N. PARK (459-144-23T)
THE WEST 140 FEET OF THE SOUTH 12 % FEET OF LOT 6 AND THE WEST 140 FEET
OF THE NORTH HALF OF LOT 5 OF BLOCK 10 OF TERRY TRACT, IN THE COUNTY
OF FRESNO, STATE OF CALIFORNIA, ACCORDING TO THE REVISED MAP OF
TERRY TRACT RECORDED IN BOOK 2, PAGE 31 OF PLATS, FRESNO COUNTY
RECORDS. EXCEPTING THEREFROM THE WEST 20 FEET THEREOF AS GRANTED
TO THE CITY OF FRESNO.
Page 34 of 57
EXHIBIT B
PROJECT DESCRIPTION AND SCHEDULE
The project will include the rehabilitation of two DEVELOPER owned homes located at 375
and 380 N. Park Avenue, in Fresno, CA 93701, and subsequent sale of the homes to low
income homebuyers, in accordance with this Agreement.
Schedule
Page 35 of 57
Dates
Finalize Scope of Work:
July 25, 2011
Advertise and Bid Project:
October 17, 2011
Award Contract:
October 19, 2011
Commencement of Rehabilitation:
October 24, 2011
Project Completion:
March 30, 2012
Listing:
Aril 30, 2012
Page 35 of 57
EXHIBIT C
EXEMPLAR: DECLARATION OF RESTRICTIONS
RECORDING REQUESTED BY AND for the benefit of
the City of Fresno and is exempt from the payment of a
recording fee in accordance with Government Code
Sections 6103 and 27383.
AND WHEN RECORDED MAIL TO:
CITY OF FRESNO
City Clerk's Office
No Fee — Govt. Code 6103
2600 Fresno Street, Room 2133
Fresno, CA 93721
APN: 459 -143 -03T&459 -144-23T
DECLARATION OF RESTRICTIONS
"375 N. Park Avenue (APN: 459-143-03T) and
380 N. Park Avenue (APN: 459-144-23T)"
THIS DECLARATION OF RESTRICTIONS, ("Declaration"), is executed as of this
by [ ], ("Declarant") in favor of the City of Fresno, acting by and
through its Downtown and Community Revitalization Department, Housing and Community
Development Division ("City').
WHEREAS, Declarant is the owner of the real estate in the County of Fresno, state
of California, consisting of APN: 459-143-03T and 459-144-23T, which is more particularly
described in Exhibit "A", attached hereto and made a part hereof (the "Property"); and
WHEREAS, Pursuant to a certain HOME Investment Partnerships Agreement dated
, 2011 incorporated herein, ("HOME Agreement") and instruments
referenced therein, Declarant agrees to utilize and City agrees to provide certain HOME
Program Funds from the United States Department of Housing and Urban Development
(HUD), to Declarant for certain affordable housing (the "Project") upon the Property to be
sold and maintained as affordable to low-income families, subject to the terms and
conditions set forth in the HOME Agreement; and
WHEREAS, the HOME Program regulations promulgated by HUD, including without
limitation 24 CFR Section 92.254, and the HOME Agreement impose certain affordability
requirements upon property benefited thereby, which affordability restrictions shall be
enforceable for a thirty (30) year period; and
WHEREAS, these restrictions are intended to bind all purchasers and their
successors.
NOW THEREFORE, Declarant declares that the Project home(s) upon the Property
Page 36 of 57
is/are held and will be held, transferred, encumbered, used, sold, conveyed and occupied
subject to the covenants, restrictions, and limitations set forth in this Declaration, all of
which are declared and agreed to be in furtherance of the plan for the rehabilitation, sale
and occupancy of the home(s) upon the Property. All of the restrictions, covenants and
limitations will run with the land and will be binding on all parties having or acquiring any
right, title or interest in the Project home upon the Property or any part thereof, will inure to
the benefit of the future Owners of the home(s) or any part thereof, the United States and
the City, and will be enforceable by any of them. Any purchaser under a contract of sale
covering any right, title or interest in any part of the Project home(s) upon the Property, by
accepting a deed or a contract of sale or agreement of purchase, accepts the document
subject to, and agrees to be bound by, any and all restrictions, covenant, and limitations set
forth in this Declaration for the period of thirty (30) years constituting the Affordability
Period.
1. Declarations. Declarant hereby declares that the home(s) upon the Property
is and shall be subject to the covenants and restrictions hereinafter set forth, all of which
are declared to be in furtherance of the Project and the HOME Agreement Project, and are
established and agreed upon for the purpose of enhancing and protecting the value of the
Project Property and in consideration for City entering into the HOME Agreement with
Declarant. All terms not otherwise defined herein shall have the meaning ascribed to such
term in the HOME Agreement.
2. Restrictions. The following covenants and restrictions on the use and
enjoyment of the Project home(s) upon the Property shall be in addition to any other
covenants and restrictions affecting the Project Property, and all such covenants and
restrictions are for the benefit and protection of City, and shall run with the home(s) upon
the Property and be binding on any future owner's of the Project home(s) upon the
Property and inure to the benefit of and be enforceable by City. These covenants and
restrictions are as follows:
a. Declarant for itself and its successor(s) on title covenants and agrees
that it shall cause the two (2) Project homes upon the Property to be used as Affordable
Housing for the duration of the Affordability Period. Declarant further agrees to file a
recordable document setting forth the Project Completion Date(s) and the Affordability
Period when determined by the City. Unless otherwise provided in the HOME Agreement,
the term Affordable Housing shall include, without limitation, compliance with the following
requirements:
Nondiscrimination. There shall be no discrimination against nor segregation
of any person or group of persons on account of race, color, creed, religion, sex, marital
status, national origin, ancestry, or handicap in the sale, transfer, use, occupancy, tenure,
or enjoyment of any of the Project Property, nor shall Declarant or any person claiming
under the Declarant, establish or permit any practice of discrimination or segregation with
reference to the selection, location, number, use or occupancy of owners or vendees of the
Project Property.
Principal Residence. Each home constituting the Project upon the Property
shall be sold only to natural persons, who shall occupy the home as the purchaser's
principal residence. The foregoing requirement that the purchaser of each home
Page 37 of 57
constituting the Project Property occupy the home as the purchaser's principal residence
does not apply to (i) persons, other than natural persons, who acquire the Project Property
or portion thereof by foreclosure or deed in lieu of foreclosure; or (ii) HUD qualified entities
that acquire the Project Property or portion thereof, with the consent of the City.
Homeowner Income Requirements. The homes constituting the Project upon
the Property and each of them may be conveyed only to (a) natural person(s) whose
annual household income at the time is not greater than eighty percent (80%) of the most
recent annual median income calculated and published by HUD for the Fresno
Metropolitan Statistical Area applicable to such household's size.
Recapture Requirements. Should any of the two (2) affordable homes upon
the Property not continue to be the principal residence of the family purchasing the
Property/home as affordable housing for the duration of the period of affordability then the
financial assistance provided by City and allocated to the Property/home including all
HOME Program Funding assistance shall immediately come due and must be repaid
to/recaptured by the City's HOME Program Trust Fund and thereupon the balance of the
affordability restrictions shall be released. The affordability restrictions also may terminate
upon occurrence of any of the following termination events: foreclosure, transfer in lieu of
foreclosure or assignment of an FHA insured mortgage to HUD, provided the affordability
restrictions shall be revived according to the original terms if, during the original affordability
period, the owner of record before such termination events obtains an ownership interest in
the housing. The City shall be possessed of a first right of refusal to purchase the home
before foreclosure to preserve affordability.
Item (a) above is hereinafter referred to as the Covenant and Restrictions.
3. Enforcement of Restrictions. Without waiver or limitation, the City shall be
entitled to injunctive or other equitable relief against any violation or attempted violation of
any Covenant and Restriction, and shall, in addition, be entitled to damages for any injuries
or losses resulting from any violations thereof.
4. Acceptance and Ratification. All present and future owners of the Project
home upon the Property and other persons claiming by, through, or under them shall be
subject to and shall comply with the Covenant and Restrictions. The acceptance of a deed
of conveyance to the Project Property shall constitute an agreement that the Covenant and
Restrictions, as may be amended or supplemented from time to time, are accepted and
ratified by such future owners, tenant or occupant, and such Covenant and Restriction shall
be a covenant running with the land'and shall bind any person having at any time any
interest or estate in the Project Property, all as though such Covenant and Restriction was
recited and stipulated at length in each and every deed, conveyance, mortgage or lease
thereof.
Notwithstanding the foregoing, upon foreclosure by a lender or other transfer
in lieu of foreclosure, or assignment of an FHA -insured mortgage to HUD, the Affordability
Period shall be terminated if the foreclosure or other transfer in lieu of foreclosure or
assignment recognizes any contractual or legal rights of public agencies, nonprofit
sponsors, or others to take actions that would avoid the termination of low-income
affordability. However, the requirements with respect to Affordable Housing shall be revived
Page 38 of 57
according to their original terms, if during the original Affordability Period, the owner of
record before the foreclosure or other transfer, or any entity that includes the former owner
or those with whom the former owner has or had formerly, family or business ties, obtains
an ownership interest in the Project or the Property, and the Affordability Period shall be
revived according to its original terms.
5. Benefit. This Declaration shall run with and bind each and both the two (2)
Project homes upon the Property for a term commencing on the date of Commencement of
the Affordability Period, as defined in the Agreement, and identified by the CITY and
expiring upon the expiration of the Affordability Period. The failure or delay at any time of
City or any other person entitled to enforce this Declaration shall in no event be deemed a
waiver of the same, or of the right to enforce the same at any time or from time to time
thereafter, or an estoppel against the enforcement thereof.
6. Costs and Attorney's Fees. In any proceeding arising because of failure of
Declarant or any future owner of the Project homes upon the Property to comply with the
Covenant and Restrictions required by this Declaration, as may be amended from time to
time, City shall be entitled to recover its costs and reasonable attorney's fees incurred in
connection with such default or failure.
7. Waiver, Neither Declarant nor any future owner of the Project homes upon
the Property may exempt itself from liability for failure to comply with the Covenant and
Restrictions required in this Declaration.
8. Severability. The invalidity of the Covenant and Restrictions or any other
covenant, restriction, condition, limitation, or other provision of this Declaration shall not
impair or affect in any manner the validity, enforceability, or effect of the rest of this
Declaration and each shall be enforceable to the greatest extent permitted by law.
9. Pronouns. Any reference to the masculine, feminine, or neuter gender herein
shall, unless the context clearly requires the contrary, be deemed to refer to and include all
genders. Words in the singular shall include and refer to the plural, and vice versa, as
appropriate.
10. Interpretation. The captions and titles of the various articles, sections,
subsections, paragraphs, and subparagraphs of this Declaration are inserted herein for
ease and convenience of reference only and shall not be used as an aid in interpreting or
construing this Declaration or any provision hereof.
11. Amendment. No amendment or modification of this Declaration shall be
permitted without the prior written consent of City.
12. Recordation. Declarant acknowledges that this Declaration will be filed of
record in the Office of the Recorder of county of Fresno, State of California.
13. Capitalized Terms. All capitalized terms used in this Declaration, unless
otherwise defined herein, shall have the meanings assigned to such terms in that certain
HOME Agreement by and between Declarant and City, of even date.
Page 39 of 57
14. Headings. The headings of the articles, sections, and paragraphs used in
this Agreement are for convenience only and shall not be read or construed to affect the
meaning or rehabilitation of any provision.
IN WITNESS WHEREOF, Declarant has executed this Declaration of Restrictions
on the date first written above.
"DECLARANT"
Housing Authority of the City of Fresno
0
Preston Prince, Executive Director
Date:
Page 40 of 57
EXHIBIT D
BUDGET
Development Item
Cost:
375 N. Park
Cost
380 N. Park
ACQUISITION — HRFC LOAN
Purchase
$53,000.00
$57,000.00
TOTAL ACQUISITION
$53,000.00
$57,000.00
RENOVATION — HOME PROGRAM
Rehabilitation Contract
$70,775.00
$72,375.00
Hard Cost Contingency — 15%
$5,662.00
$5,790.00
TOTAL HARD COSTS
$76,437.00
$78,165.00
Developer Fee — HOME PROGRAM
$7,644.00
$7,817.00
TOTAL COSTS DURING RENOVATION
$137,081.00
$142,982.00
Page 41 of 57
EXHIBIT E
EXEMPLAR CERTIFICATE OF COMPLETION
RECORDED AT THE REQUEST OF
AND WHEN RECORDED RETURN
TO:
City of Fresno
Housing Division
2600 Fresno Street, Room 3070
Fresno, CA 93721
This Certificate of Completion is recorded at the request and for the benefit of the City of
Fresno and is exempt from the payment of a recording fee pursuant to Government
Code Section 6103.
MWI
City of Fresno
By:
Director
Development and Resource Management Department
Date:
Page 42 of 57
CERTIFICATE OF COMPLETION
APN:
Recitals:
A. By a HOME Program Agreement dated , 2011, ("HOME Agreement")
between the City of Fresno, a municipal corporation ("CITY"), and the Housing Authority of
the City of Fresno, a California public agency (hereinafter referred to as "DEVELOPER"),
the DEVELOPER agreed to rehabilitate and resell two single family homes located at 375
and 380 N. Park Avenue, Fresno, Ca 93721 ("Project"), upon the Project Property as pre -
approved by the CITY, for the sale of the Affordable Units to low income homebuyers, with
the assistance of HOME funds while meeting the affordable housing, income targeting and
other requirements of HOME regulations, according to the terms and conditions of the
HOME Agreement and the Loan Documents and other document/instruments referenced
therein.
B. The HOME Agreement or a memorandum of it was recorded on
__, 2011 as Instrument No. in the Official Records of Fresno County,
California.
C. Under the terms of the HOME Agreement, after the DEVELOPER completes the
rehabilitation and upon opening of escrow for a Project Property, the DEVELOPER may
ask CITY to record a Certificate of Completion.
D. The DEVELOPER has asked CITY to furnish the DEVELOPER with a recordable
Certificate of Completion.
E. The CITY's issuance of this Certificate of Completion is conclusive evidence that the
DEVELOPER has completed rehabilitation/rehabilitation of the Property as set forth in the
HOME Agreement.
NOW THEREFORE:
1. CITY certifies that the DEVELOPER commenced the rehabilitation of the
Project Property on 20_ and completed the rehabilitation work on
the Project Property on 20_, and has done so in full compliance
with the HOME Agreement.
2. This Certificate of Completion is not evidence of the DEVELOPER
compliance with, or satisfaction of, any obligation to any mortgage or security interest
holder, or any mortgage or security interest insurer, securing money lent to finance work on
the Property or Project, or any part of the Property or Project.
3. This Certificate of Completion is not a notice of completion as referred to in
California Civil Code Section 3093.
4. Nothing contained herein modifies any provision of the HOME Agreement.
Page 43 of 57
IN WITNESS WHEREOF, CITY has executed this Certificate of Completion as of
this day of , 20_
CITY OF FRESNO
M
, Director
Development and Resource Management Department
ATTEST:
CITY CLERK
By:
Deputy
Date:
CONSENT OF OWNER/DEVELOPER
Housing Authority of the City of Fresno
By:
(Attach notary certificate of acknowledgment)
Preston Prince, Executive Director
Date:
APPROVED AS TO FORM:
JAMES C. SANCHEZ
Robert Coyle, Deputy City Attorney
Date:
Page 44 of 57
EXHIBIT F1
EXEMPLAR NOTE AND TEMPLATE RIDER TO DEED OF TRUST
DO NOT DESTROY THIS NOTE: When paid, this note must be surrendered to Borrower
for Cancellation.
PROMISSORY NOTE
$84,081.00
APN: 459-143-03T
Fresno, California
February 11, 2010
Promise to Pay. For value received, the undersigned, Housing Authority of the City of
Fresno, Inc., a California Public Agency ("Developer" or "Borrower"), promises to pay to the
order of the City of Fresno, a California municipal corporation, ("Lender"), the sum of Eighty
Four Thousand Eighty One Dollars and 00/100 ($84,081.00) along with interest on unpaid
principal at the rate of 2% per annum, all due and payable on or before December 31,
2012, (the "Developer Loan Maturity Date") pursuant to the parties' HOME Investment
Partnerships Program Agreement dated September 29, 2011 ("HOME Agreement"), on
which date the unpaid principal balance together with interest and unpaid penalties or late
charges where applicable thereon shall be due and payable, along with attorney's fees and
costs of collection, without relief from valuation and appraisement laws; provided that, in
the event the Developer is not then in default of the HOME Agreement, the Developer may
at any time prior to the Developer Loan Maturity Date convey the completed Unit securing
the Note to a Low Income buyer through a purchase escrow (Escrow) that conforms to the
HOME Agreement and concurrent therewith assign this Note to the Low Income Buyer,
who shall assume such Note at 0% interest with lump sum principal only payment due and
payable from the Low Income Buyer on or before 30 years from close of the homebuyer's
purchase escrow ("Low Income Homebuyer Loan Maturity Date"). In that event, and
concurrent therewith, the City shall forgive from principal due thereunder (and shall not
recapture) [the difference between a fair market appraisal of the Unit and the total project
cost, the "Development Subsidy, provided the DEVELOPER confirms said Development
Subsidy reduction in writing noticed to the Escrow Office and the City in the manner
provided for in the HOME Agreement, and the DEVELOPER shall be released from any
further liability to the Lender under this Note, including as to any interest accrued prior to
assumption of the Note by the Low Income Homebuyer. Any failure to make a payment
required hereunder shall constitute a default under this Note.
Definitions. All capitalized terms used in this Note, unless otherwise defined, will have the
respective meanings specified in the HOME Agreement.
Business Day. Means any day other than Saturday, Sunday, or public holiday or the
equivalent for banks generally under the laws of California. Whenever any payment to be
made under this Note is stated to be due on a day other than a Business Day, that
payment may be made on the next succeeding Business Day. However, if the extension
would cause the payment to be made in a new calendar month, that payment will be made
on the next preceding Business Day.
Page 45 of 57
Security. This Note, and any extensions or renewals hereof, is secured by a Deed of Trust,
Security Agreement and Fixture Filing with Assignment of Rents executed by Borrower and
recorded against the Property in Fresno County, California, as Document No, TO BE
FILLED IN AT A LATER DATE, that provides for acceleration upon stated events, and
executed in favor of the Lender ("Deed of Trust"), creating and insured as a not worse than
2nd position lien on the Property, subordinated only to a lien created by Borrower to insure
payment of monies borrowed to pay for the rehabilitation of a completed Unit on the
Property. Said Deed of Trust shall be subject to the terms of the Template Rider to the
Deed of Trust attached hereto, and such shall automatically be incorporated in the terms of
the Deed of Trust that secures this Note. Said Deed of Trust is insured by CLTA Lender's
policy in the principal amount of, and endorsed for this Note.
Time is of the Essence. It will be a default under this Note if Borrower defaults under the
HOME Agreement, defaults under any other Loan Documents, or if Borrower fails to pay
when due any sum payable under this Note. In the event of a default by Borrower, the
Borrower shall pay a late charge equal to the lesser of 2% of any outstanding payment or
the maximum amount allowed by law. All payments collected shall be applied first to
payment of any costs, fees or other charges due under this Note or any other Loan
Documents then to the interest and then to principal balance. On the occurrence of a
default or on the occurrence of any other event that under the terms of the Loan
Documents give rise to the right to accelerate the balance of the indebtedness, then, at the
option of Lender, this Note or any notes or other instruments that may be taken in renewal
or extension of all or any part of the indebtedness will immediately become due without any
further presentment, demand, protest, or notice of any kind.
Terms of Payment. The indebtedness evidenced by this Note may, at the option of the
Borrower, be prepaid in whole or in part without penalty. Lender will apply all the
prepayments first to the payment of any costs, fees, late charges, or other charges due
under this Note or under any of the other Loan Documents and then to the interest and
then to the principal balance.
All Loan payments are payable in lawful money of the United States of America at any
place that Lender or the legal holders of this Note may, from time to time, in writing
designate, and in the absence of that designation, to:
City of Fresno - Finance
Accounts Receivable
2600 Fresno Street, Suite 2156
Fresno, CA 93721
Borrower agrees to pay all costs including, without limitation, attorney fees, incurred by the
holder of this Note in enforcing payment, whether or not suit is filed, and including, without
limitation, all costs, attorney fees, and expenses incurred by the holder of this Note in
connection with any bankruptcy, reorganization, arrangement, or other similar proceedings
involving the undersigned that in any way affects the exercise by the holder of this Note of
its rights and remedies under this Note. All costs incurred by the holder of this Note in any
action undertaken to obtain relief from the stay of bankruptcy statutes are specifically
included in those costs and expenses to be paid by Borrower. Borrower will pay to Lender
Page 46 of 57
all attorney fees and other costs referred to in this paragraph on demand.
Any notice, demand, or request relating to any matter set forth herein shall be in writing and
shall be given as provided in the HOME Agreement. No delay or omission of Lender in
exercising any right or power arising in connection with any default will be construed as a
waiver or as acquiescence, nor will any single or partial exercise preclude any further
exercise. Lender may waive any of the conditions in this Note and no waiver will be
deemed to be a waiver of Lender's rights under this Note, but rather will be deemed to
have been made in pursuance of this Note and not in modification. No waiver of any
default will be construed to be a waiver of or acquiescence in or consent to any preceding
or subsequent default.
Terms of Security Instruments. The Deed of Trust securing this note provides as follows:
DUE ON SALE—CONSENT BY BENEFICIARY. Beneficiary may, at its option, declare
immediately due and payable all sums secured by this Deed of Trust upon the sale or
transfer of all or any portion of the Property, or any interest therein, other than a sale to a
Low Income homebuyer as provided in the HOME Agreement, without the Beneficiary's
prior consent. A "sale or transfer" means the conveyance of the Property or any right, title
or interest therein; whether legal, beneficial or equitable; whether voluntary or involuntary;
whether by outright sale, deed, installment sale contract, land contract, contract for deed,
leasehold interest with a term greater than three (3) years, lease-option contract, or by
sale, assignment, or transfer of any beneficial interest in or to any land trust holding title to
the Property, or by any other method of conveyance of land interest. If any Trustor is a
corporation, partnership or limited liability, company, transfer also includes any change in
ownership of more than twenty-five percent (25%) of the voting stock, partnership interests
or limited liability company interests, as the case may be, of Trustor. However, this option
shall not be exercised by Beneficiary if such exercise is prohibited by applicable law.
Assignment by Lender. Lender may transfer this Note and deliver to the transferee all or
any part of the Property then held by it as security under this Note, and the transferee will
then become vested with all the powers and rights given to Lender; and Lender will then be
forever relieved from any liability or responsibility in the matter, but Lender will retain all
rights and powers given by this Note with respect to Property not transferred.
Enforceablilty. If any one or more of the provisions in this Note is held to be invalid, illegal,
or unenforceable in any respect by a court of competent jurisdiction, the validity, legality,
and enforceability of the remaining provisions will not in any way be affected or impaired.
This Note will be binding on and inure to the benefit of Borrower, Lender, and their
respective successors and assigns.
Governing Law. Borrower agrees that this Note will be deemed to have been made under
and will be governed by the laws of California in all respects, including matters of
rehabilitation, validity, and performance, and that none of its terms or provisions may be
waived, altered, modified, or amended except as Lender may consent to in a writing duly
signed by Lender or its authorized agents.
Page 47 of 57
In witness whereof, Borrower has caused this Promissory Note to be executed by its
authorized agent as of the date and year first above written.
Housing Authority of the City of Fresno, Borrower
By: Date:
(Attach notary certificate of acknowledgment)
Name: Preston Prince
Title: Executive Director
Page 48 of 57
[TEMPLATE RIDER TO DEED(S) OF TRUST]
The Trustor (herein "Borrower") understands and agrees that the Note secured by this
Deed of Trust is made for the sole purpose of assisting in the purchase of the Borrower's
home as their principal place of residence. Therefore, the Borrower understands and
agrees that said Note secured by this Deed of Trust shall be immediately due and payable
upon the earlier of (1) upon any change in residency of the Borrower from the Borrower's
home used as security for the Note described above, unless having obtained the written
consent of the Beneficiary (herein "Lender"); (2) upon the sale or transfer, without the
Lender's prior written consent, of all or any part of the Property, or any interest in the
Property. A "sale or transfer" means the conveyance of the Property or any right, title or
interest therein; whether legal, beneficial or equitable; whether voluntary or involuntary;
whether by outright sale, deed, installment sale contract, land contract, contract for deed,
lease -option contract, or by sale, assignment, or transfer of any beneficial interest in or to
any land trust holding title to the Property, or by any other method of conveyance of land
interest.
Borrower also assigns to Lender all rents, issues and profits from said real property
reserving, however, the right to collect and use the same so long as there is no existing
default hereunder, and does hereby authorize Lender to collect and recover the same in
the name of Borrower of his successor in interest by use of any lawful means.
The Lender and Borrower acknowledge and agree that this security instrument is second
and subordinate in all respects to the liens, terms, covenants and conditions of the first
Deed of Trust and shall not impair the rights of any institutional lender which is the maker of
a loan secured by such first deed of trust, or such lender's assignee or successor in
interest, to exercise its remedies under the deed of trust in the event of default by the
Borrower.
These remedies include the right to foreclosure or exercise a power of sale or to accept a
deed or assignment in lieu of foreclosure. The terms and provisions of the first Deed of
Trust are paramount and controlling, and they supersede any other terms and provisions
hereof in conflict therewith.
In the event of a catastrophic occurrence that results in the property having to be sold, the
portion of this existing second mortgage lien that results in the combined loan -to -value ratio
being more than 100% of the value of the property will be released with no forgiveness of
that portion of the debt, and the contemporaneous execution of an unsecured promissory
note equal to the amount released from the second mortgage, and a modification
agreement that reduces the secured debt of the existing second mortgage by the amount
of the new unsecured promissory note.
Period of Affordability: The HOME Investment Partnerships Program sets periods of
affordability as provided in 24 CFR 92.254 based on the amount of HOME funds provided.
The minimum period of affordability for this program is thirty years (30 years.) Year one
shall be the 12 -month period following the date the City identifies as the start of the
Affordability Period, as defined in the Agreement, with each succeeding year beginning on
the anniversary thereof and ending 12 month hence. There will be no partial years.
Page 49 of 57
Recapture of HOME Funds: Pursuant to 24 CFR 92.254(a)(5)(ii), the City of Fresno
requires that HOME funds be recaptured if the home does not continue to be the
Borrower's principal residence or if all or any part of the property or any interest in it is sold,
rented, conveyed or transferred for the duration of the Period of Affordability.
Foreclosure Proceedings:
In the event of a foreclosure, deed in lieu of foreclosure of the first Deed of Trust or short
sale, any provisions herein or any provisions in any other collateral agreement restricting
the use of the property to low income households or otherwise restricting the Borrower's
ability to sell the property shall have no further force or effect on subsequent owners or
purchasers of the property. Any person, including his successors or assigns (other than
the Borrower or a related entity of the Borrower), receiving title to the property through a
foreclosure, or deed in lieu of foreclosure of the first Deed of Trust or short sale shall
receive title to the property free and clear from such restrictions.
If the net proceeds in a foreclosure, deed in lieu of foreclosure of the first Deed of Trust or
short sale, are not sufficient to recapture the full HOME investment plus enable the
homeowner to recover the amount of the homeowner's downpayment and any capital
improvement investment made by the owner since purchase, the City of Fresno may share
the net proceeds. The net proceeds are the sales price minus superior loan repayment
(other than HOME funds) and any closing costs. The net proceeds may be divided
proportionally as set forth in the following mathematical formulas:
HOME investment
HOME investment + x Net proceeds = HOME amount to be recaptured
homeowner investment
Homeowner investment
HOME investment + x Net proceeds = amount to homeowner
homeowner investment
Page 50 of 57
EXHIBIT F2
EXEMPLAR NOTE AND TEMPLATE RIDER TO DEED OF TRUST
DO NOT DESTROY THIS NOTE: When paid, this note must be surrendered to Borrower
for Cancellation.
PROMISSORY NOTE
$85,982.00
APN: 459-144-23T
Fresno, California
2011
Promise to Pay. For value received, the undersigned, Housing Authority of the City of
Fresno, Inc., a California Public Agency ("Developer" or "Borrower"), promises to pay to the
order of the City of Fresno, a California municipal corporation, ("Lender"), the sum of Eighty
Five Thousand Nine Hundred Eighty Two Dollars and 00/100 ($85,982.00) along with
interest on unpaid principal at the rate of 2% per annum, all due and payable on or before
0_ - $ \ - i ti , (the "Developer Loan Maturity Date") pursuant to the parties' HOME
Investment Partnerships Program Agreement dated , 2011 ("HOME
Agreement"), on which date the unpaid principal balance together with interest and unpaid
penalties or late charges where applicable thereon shall be due and payable, along with
attorney's fees and costs of collection, without relief from valuation and appraisement laws;
provided that, in the event the Developer is not then in default of the HOME Agreement, the
Developer may at any time prior to the Developer Loan Maturity Date convey the
completed Unit securing the Note to a Low Income buyer through a purchase escrow
(Escrow) that conforms to the HOME Agreement and concurrent therewith assign this Note
to the Low Income Homebuyer, who shall assume such Note at 0% interest with lump sum
principal only payment due and payable from the Low Income Buyer on or before 30 years
from close of the homebuyer's purchase escrow ("Low Income Homebuyer Loan Maturity
Date"). In that event, and concurrent therewith, the City shall forgive from principal due
thereunder (and shall not recapture) [the difference between a fair market appraisal of the
Unit and the total project cost, the "Development Subsidy, provided the DEVELOPER
confirms said Development Subsidy reduction in writing noticed to the Escrow Office and
the City in the manner provided for in the HOME Agreement, and the DEVELOPER shall
be released from any further liability to the Lender under this Note, including as to any
interest accrued prior to assumption of the Note by the Low Income Homebuyer. Any
failure to make a payment required hereunder shall constitute a default under this Note.
Definitions. All capitalized terms used in this Note, unless otherwise defined, will have the
respective meanings specified in the HOME Agreement.
Business Day. Means any day other than Saturday, Sunday, or public holiday or the
equivalent for banks generally under the laws of California. Whenever any payment to be
made under this Note is stated to be due on a day other than a Business Day, that
payment may be made on the next succeeding Business Day. However, if the extension
would cause the payment to be made in a new calendar month, that payment will be made
on the next preceding Business Day,
Security. This Note, and any extensions or renewals hereof, is secured by a Deed of Trust,
Page 51 of 57
Security Agreement and Fixture Filing with Assignment of Rents executed by Borrower and
recorded against the Property in Fresno County, California, as Document No. TO BE
FILLED IN AT A LATER DATE, that provides for acceleration upon stated events, and
executed in favor of the Lender ("Deed of Trust"), creating and insured as a not worse than
2nd position lien on the Property, subordinated only to a lien created by Borrower to insure
payment of monies borrowed to pay for the rehabilitation of a completed Unit on the
Property. Said Deed of Trust shall be subject to the terms of the Template Rider to the
Deed of Trust attached hereto, and such shall automatically be incorporated in the terms of
the Deed of Trust that secures this Note. Said Deed of Trust is insured by CLTA Lender's
policy in the principal amount of, and endorsed for this Note.
Time is of the Essence. It will be a default under this Note if Borrower defaults under the
HOME Agreement, defaults under any other Loan Documents, or if Borrower fails to pay
when due any sum payable under this Note. In the event of a default by Borrower, the
Borrower shall pay a late charge equal to the lesser of 2% of any outstanding payment or
the maximum amount allowed by law. All payments collected shall be applied first to
payment of any costs, fees or other charges due under this Note or any other Loan
Documents then to the interest and then to principal balance. On the occurrence of a
default or on the occurrence of any other event that under the terms of the Loan
Documents give rise to the right to accelerate the balance of the indebtedness, then, at the
option of Lender, this Note or any notes or other instruments that may be taken in renewal
or extension of all or any part of the indebtedness will immediately become due without any
further presentment, demand, protest, or notice of any kind.
Terms of Payment. The indebtedness evidenced by this Note may, at the option of the
Borrower, be prepaid in whole or in part without penalty. Lender will apply all the
prepayments first to the payment of any costs, fees, late charges, or other charges due
under this Note or under any of the other Loan Documents and then to the interest and
then to the principal balance.
All Loan payments are payable in lawful money of the United States of America at any
place that Lender or the legal holders of this Note may, from time to time, in writing
designate, and in the absence of that designation, to:
City of Fresno - Finance
Accounts Receivable
2600 Fresno Street, Suite 2156
Fresno, CA 93721
Borrower agrees to pay all costs including, without limitation, attorney fees, incurred by the
holder of this Note in enforcing payment, whether or not suit is filed, and including, without
limitation, all costs, attorney fees, and expenses incurred by the holder of this Note in
connection with any bankruptcy, reorganization, arrangement, or other similar proceedings
involving the undersigned that in any way affects the exercise by the holder of this Note of
its rights and remedies under this Note. All costs incurred by the holder of this Note in any
action undertaken to obtain relief from the stay of bankruptcy statutes are specifically
included in those costs and expenses to be paid by Borrower. Borrower will pay to Lender
all attorney fees and other costs referred to in this paragraph on demand.
Any notice, demand, or request relating to any matter set forth herein shall be in writing and
Page 52 of 57
shall be given as provided in the HOME Agreement. No delay or omission of Lender in
exercising any right or power arising in connection with any default will be construed as a
waiver or as acquiescence, nor will any single or partial exercise preclude any further
exercise. Lender may waive any of the conditions in this Note and no waiver will be
deemed to be a waiver of Lender's rights under this Note, but rather will be deemed to
have been made in pursuance of this Note and not in modification. No waiver of any
default will be construed to be a waiver of or acquiescence in or consent to any preceding
or subsequent default.
Terms of Security Instruments. The Deed of Trust securing this note provides as follows:
DUE ON SALE—CONSENT BY BENEFICIARY. Beneficiary may, at its option, declare
immediately due and payable all sums secured by this Deed of Trust upon the sale or
transfer of all or any portion of the Property, or any interest therein, other than a sale to a
Low Income homebuyer as provided in the HOME Agreement, without the Beneficiary's
prior consent. A "sale or transfer" means the conveyance of the Property or any right, title
or interest therein; whether legal, beneficial or equitable; whether voluntary or involuntary;
whether by outright sale, deed, installment sale contract, land contract, contract for deed,
leasehold interest with a term greater than three (3) years, lease-option contract, or by
sale, assignment, or transfer of any beneficial interest in or to any land trust holding title to
the Property, or by any other method of conveyance of land interest. If any Trustor is a
corporation, partnership or limited liability, company, transfer also includes any change in
ownership of more than twenty-five percent (25%) of the voting stock, partnership interests
or limited liability company interests, as the case may be, of Trustor. However, this option
shall not be exercised by Beneficiary if such exercise is prohibited by applicable law.
Assignment by Lender. Lender may transfer this Note and deliver to the transferee all or
any part of the Property then held by it as security under this Note, and the transferee will
then become vested with all the powers and rights given to Lender; and Lender will then be
forever relieved from any liability or responsibility in the matter, but Lender will retain all
rights and powers given by this Note with respect to Property not transferred.
Enforceablilty. If any one or more of the provisions in this Note is held to be invalid, illegal,
or unenforceable in any respect by a court of competent jurisdiction, the validity, legality,
and enforceability of the remaining provisions will not in any way be affected or impaired.
This Note will be binding on and inure to the benefit of Borrower, Lender, and their
respective successors and assigns.
Governinq Law. Borrower agrees that this Note will be deemed to have been made under
and will be governed by the laws of California in all respects, including matters of
rehabilitation, validity, and performance, and that none of its terms or provisions may be
waived, altered, modified, or amended except as Lender may consent to in a writing duly
signed by Lender or its authorized agents.
Page 53 of 57
In witness whereof, Borrower has caused this Promissory Note to be executed by its
authorized agent as of the date and year first above written.
Housing Authority of the City of Fresno, Borrower
By: Date:
(Attach notary certificate of acknowledgment)
Name: Preston Prince
Title: Executive Director
Page 54 of 57
[TEMPLATE RIDER TO DEED(S) OF TRUST)
The Trustor (herein "Borrower") understands and agrees that the Note secured by this
Deed of Trust is made for the sole purpose of assisting in the purchase of the Borrower's
home as their principal place of residence. Therefore, the Borrower understands and
agrees that said Note secured by this Deed of Trust shall be immediately due and payable
upon the earlier of (1) upon any change in residency of the Borrower from the Borrower's
home used as security for the Note described above, unless having obtained the written
consent of the Beneficiary (herein "Lender"); (2) upon the sale or transfer, without the
Lender's prior written consent, of all or any part of the Property, or any interest in the
Property. A "sale or transfer" means the conveyance of the Property or any right, title or
interest therein; whether legal, beneficial or equitable; whether voluntary or involuntary;
whether by outright sale, deed, installment sale contract, land contract, contract for deed,
lease -option contract, or by sale, assignment, or transfer of any beneficial interest in or to
any land trust holding title to the Property, or by any other method of conveyance of land
interest.
Borrower also assigns to Lender all rents, issues and profits from said real property
reserving, however, the right to collect and use the same so long as there is no existing
default hereunder, and does hereby authorize Lender to collect and recover the same in
the name of Borrower of his successor in interest by use of any lawful means.
The Lender and Borrower acknowledge and agree that this security instrument is second
and subordinate in all respects to the liens, terms, covenants and conditions of the first
Deed of Trust and shall not impair the rights of any institutional lender which is the maker of
a loan secured by such first deed of trust, or such lender's assignee or successor in
interest, to exercise its remedies under the deed of trust in the event of default by the
Borrower.
These remedies include the right to foreclosure or exercise a power of sale or to accept a
deed or assignment in lieu of foreclosure. The terms and provisions of the first Deed of
Trust are paramount and controlling, and they supersede any other terms and provisions
hereof in conflict therewith.
In the event of a catastrophic occurrence that results in the property having to be sold, the
portion of this existing second mortgage lien that results in the combined loan -to -value ratio
being more than 100% of the value of the property will be released with no forgiveness of
that portion of the debt, and the contemporaneous execution of an unsecured promissory
note equal to the amount released from the second mortgage, and a modification
agreement that reduces the secured debt of the existing second mortgage by the amount
of the new unsecured promissory note.
Period of Affordability: The HOME Investment Partnerships Program sets periods of
affordability as provided in 24 CFR 92.254 based on the amount of HOME funds provided.
The minimum period of affordability for this program is thirty years (30 years.) Year one
shall be the 12 -month period following the date the City identifies as the start of the
Affordability Period, as defined in the Agreement, with each succeeding year beginning on
the anniversary thereof and ending 12 month hence. There will be no partial years.
Page 55 of 57
Recapture of HOME Funds: Pursuant to 24 CFR 92.254(a)(5)(ii), the City of Fresno
requires that HOME funds be recaptured if the home does not continue to be the
Borrower's principal residence or if all or any part of the property or any interest in it is sold,
rented, conveyed or transferred for the duration of the Period of Affordability.
Foreclosure Proceedings:
In the event of a foreclosure, deed in lieu of foreclosure of the first Deed of Trust or short
sale, any provisions herein or any provisions in any other collateral agreement restricting
the use of the property to low income households or otherwise restricting the Borrower's
ability to sell the property shall have no further force or effect on subsequent owners or
purchasers of the property. Any person, including his successors or assigns (other than
the Borrower or a related entity of the Borrower), receiving title to the property through a
foreclosure, or deed in lieu of foreclosure of the first Deed of Trust or short sale shall
receive title to the property free and clear from such restrictions.
If the net proceeds in a foreclosure, deed in lieu of foreclosure of the first Deed of Trust or
short sale, are not sufficient to recapture the full HOME investment plus enable the
homeowner to recover the amount of the homeowner's downpayment and any capital
improvement investment made by the owner since purchase, the City of Fresno may share
the net proceeds. The net proceeds are the sales price minus superior loan repayment
(other than HOME funds) and any closing costs. The net proceeds may be divided
proportionally as set forth in the following mathematical formulas:
HOME investment
HOME investment + x Net proceeds = HOME amount to be recaptured
homeowner investment
Homeowner investment
HOME investment + x Net proceeds = amount to homeowner
homeowner investment
Page 56 of 57
EXHIBIT G
GUIDE TO REHABILITATION STANDARDS
ARE REFERENCED AND AVAILABLE UPON REQUEST TO THE CITY OF
FRESNO'S HOUSING AND COMMUNITY DEVELOPMENT DIVISION
Page 57 of 57
City of
r"■"1i� ill: = ��►� REPORT TO THE CITY COUNCIL
AGENDA ITEM NO. 1: 30pm :#=4
COUNCIL MEETING: 9-29-11
APPROVED BY
fel % �""`"
D W MENT DIRECT
CITY N
September 29, 2011
%
FROM: CRAIG SCHARTON, Assistant Director
Development and Resource Management Department
BY: CLAUDIA CAZARES, Manager
Housing and Community Development Division
SUBJECT: ADOPT A FINDING OF CATEGORICAL EXEMPTION, PURSUANT TO ARTICLE 19,
SECTION 15301/CLASS 1 (REPAIR OF EXISTING FACILITIES) AND 15312/CLASS 12 (SALE
OF GOVERNMENT PROPERTY), OF THE CEQA GUIDELINES AND APPROVE A HOME
INVESTMENT PARTNERSHIPS PROGRAM AGREEMENT WITH THE HOUSING
AUTHORITY OF THE CITY OF FRESNO IN THE AMOUNT OF $170,063 FOR
REHABILITATION OF TWO SINGLE-FAMILY HOMES IN THE LOWELL NEIGHBORHOOD.
Presentee! to City cou�01
RECOMMENDATIONS Date`�.�! - —
Disposition
Staff recommends that City Council:
Adopt a Finding of Categorical Exemption pursuant to CEQA guidelines Section 15301 and 15312;
and
2, Approve a Home Investment Partnerships (HOME) Program Agreement (please see Exhibit A --
HOME Agreement) with the Housing Authority of the City of Fresno (Developer) in the amount of
$170,063 for the rehabilitation of two single family homes, located at 375 and 380 N. Park Avenue,
in the Lowell Neighborhood, subject to City Attorney approval to form.
EXECUTIVE SUMMARY
The City has received a funding request from the Housing Authority of the City of Fresno for $170,063 in
HOME Program funds to rehabilitate two single family homes, located at 375 and 380 N. Park Avenue (please
see Exhibit B – Pictures). The homes were previously purchased by the developer. Once the homes have
been rehabilitated, the developer will sell them to low-income households. The total project cost is estimated
at $280,063, which includes property purchase and rehabilitation costs. Staff has determined that the project
is categorically exempt pursuant to California Environmental Quality Act (CEQA) guidelines.
BACKGROUND
CEQA and NEPA Compliance
The City has conducted an environmental review of the project pursuant to the National Environmental Policy
Act, resulting in a finding of Categorical Exclusion (Environmental Assessment No. H-2011-02). The City has
REPORT TO THE CITY COUNCIL
HOME Agreement with Housing Authority 375/380 N. Park
September 29, 2011
Page 2
also conducted an environmental review of the project pursuant to the California Environmental Quality Act,
resulting in a Categorical Exemption pursuant to Section 15301 — Class 1, which exempts operation, repair,
maintenance, permitting, leasing, licensing, or minor alteration of existing public or private structures, facilities,
mechanical equipment, or topographical features, involving negligible or no expansion of use beyond that
existing at the time of the lead agency's determination. This project also falls within the Class 12 Categorical
Exemption set forth in the CEQA Guidelines, Section 15312 which exempts sales of surplus government
property except for parcels of land located in an area of statewide, regional, or area wide concern identified in
Section 15206(b)(4). No adverse environmental impacts would occur as a result of the proposed project.
Project Background
City staff has been collaborating with the developer to revitalize the Lowell and Downtown area, and as part of
these efforts, the developer purchased the two single -story bungalow style homes on Park Avenue with the
intent to rehabilitate them and resell them to two low-income families. By investing in the community the
developer hopes to nurture pride of ownership and stabilize the neighborhood.
Additionally, the developer has partnered with Fresno City College on this project. The Fresno City College
program, called "Housing Re -Construction Program" is funded through a grant from HUD - Outreach and
University Partnerships. College students will be performing the rehabilitation work of the house under the
direction of their trainer, a licensed General Contractor. This effort will provide valuable workplace experience
for the students in the training program at the same time offering an economical approach to the city's efforts to
revitalize neighborhoods. The Program's mission is to positively impact our community by rehabilitating homes
in blighted neighborhoods, while providing adults with college level course work coupled with hands-on training
in the area of basic housing reconstruction with a focus on employment readiness.
The homes on 375 and 380 N. Park have been vacant for over a year, and were abandoned when the
developer purchased them. The home at 375 N. Park is a two bedroom one bath home built in 1930.
The home at 380 N. Park is a three bedroom, 1.5 bathroom home built in 1922. Rehabilitation of both
homes will be required to keep their historic integrity to the highest extent possible. Additional work
required on the homes, per federal regulation, include health, safety and code items such as: termite
damage repair, lead assessment, repair and clearance, asbestos repair, roofing repair, air conditioning,
windows, electrical, water heater, basement access and crawl space, carports, driveway repairs and
landscaping, among other items (please see Exhibit C — Proposed Scope of Work, for each home).
Construction/Rehabilitation costs for the homes is estimated at $70,000 each. Total costs for the home
on 375 N. Park is $137,081, which includes the property purchase price. Total costs for the home on 380
N. Park is $142,982, which also includes the property purchase price.
Once rehabilitation is complete, the developer will sell the homes to two low-income households. As part
of the transaction the City will forgive a portion of the note (amount to be determined at sale) to
accommodate for the difference between the City's investment, the developer's investment and the
appraised value of the home at the time of re -sale. The loan forgiveness is the only option to
accommodate for the current value of homes in the area, and ensure that the home is available to resale
to a low-income homebuyer. Upon conveyance of the Note to the homebuyer, the terms will convert to a 30
year deferred loan at zero percent interest.
The City considers the HOME funds invested in the properties as an investment in the neighborhood that is
expected to spur further private investment in the neighborhood. HOME funds to be invested in the project are
above what a typical private investor will consider for such a project, but are aligned with the intended use of
HOME Program funding.
2
REPORT TO THE CITY COUNCIL
HOME Agreement with Housing Authority 375/380 N. Park
September 29, 2011
Page 3
HOUSING AND COMMUNITY DEVELOPMENT
The Housing and Community Development Commission reviewed and recommended the item for Council
approval on August 24, 2011.
FISCAL IMPACT
Funding for this project is currently available in the Development and Resource Management Department's FY
2012 Budget. Total cost for the project is $280,063.
Attachments:
Exhibit A — HOME Agreement
Exhibit B — Pictures of Homes
KAHOUSING\PROCEDURES MANUAL\CHAPTER_21 HCDC & Council\COUNCIL\2011\Council Report 375-380 N Park Housing Authority Agreement 9-29-11
3